Fill - Free fillable Judson Nature Trail Building Bid Set 09.12.2018 (City of Alamo Heights) PDF form

CITY OF ALAMO HEIGHTS

6116 Broadway

San Antonio, Texas 78209

210-822-3331

FAX 210-822-8197

CITY OF ALAMO HEIGHTS

6116 Broadway

San Antonio, TX 78209

CITY OF ALAMO HEIGHTS, TEXAS

SEEKING SEALED BIDS

FOR RENOVATIONS TO NATURE TRAILS BUILDING

The City of Alamo Heights is soliciting bids for the renovation of building located at the Judson

Nature Trails, 246 Viesca, to include removal and replacement of existing metal roof and all rotted

tongue and grove timber and sheathing, renovate bathrooms to meet ADA requirements,

update/install lighting and electrical wiring along overhand and within display cases and repaint

existing soffit, window and frames and doors.

Sealed bids will be received until 2:00 p.m., Friday, October 12, 2018 by the City Secretary at

City Hall, 6116 Broadway. The bids will be publicly opened and read aloud at this time and place.

Bids received after this time will be returned unopened. Address packets to City Secretary –

Jennifer Reyna. Competitive sealed bids shall be marked “Nature Trail Building”.

Submittal packets may be obtained at City Hall – 6116 Broadway or on the City’s website

https://www.alamoheightstx.gov/departments/administration-and-finance/rfps-rfqs-bids/

Questions may be directed to Marian V. Mendoza, Assistant to the City Manager at

mmendoza@alamoheightstx.gov.

A non-mandatory pre-bid conference for the project will be held on Wednesday, September 19,

2018, at 10:00 a.m. at Judson Nature Trails Building – 246 Viesca, Alamo Heights, TX 78209.

Jennifer Reyna

City Secretary

RequestforSealedBid 

CityofAlamoHeightsJudsonNatureTrailBuilding09/12/18

October2018

REQUESTFORSEALEDBIDS

ARTICLE1: GENERALNOTICE

1.01 TheCityofAlamoHeightsisrequestingSealedBidsforthefollowingproject:

RenovationofJudsonNatureTrailsBuilding

246Viesca,AlamoHeights,Texas78209

A. This project includes all work included but not limited to‐

Furnish all labor, tools,

equipment, materials andincidentals to remove and replace of existing metal roof and all

rotted tongue, grove timber, sheathing, renovate bathrooms to meet ADA requirements,

update/installlightingandelectricalwiringalongoverhandandwithindisplaycases,repaint

existingsoffit,windows,framesanddoors.Allaccordancewiththe

BiddingDocument.

1.02 Sealed Bids must be delivered to the City Secretary of the City of Alamo Heights at 6116

Broadway,SanAntonio,Texas78209nolaterthan2:00p.m.,October12,2018tobeaccepted.

TheSealedBidswillbepubliclyopenedandreadaloudatthistimeandplace.Bidsreceivedafter

thistimewillbereturnedunopened.Bidsmustbeenclosedinasealedenvelope,boxorcontainer

clearlymarkedontheoutsideasan“JudsonNatureTrailsBuilding”andshallincludethefollowing



information:Attn:CitySecretary,ProjectName,ProjectLocation,BidOpeningDateandTime.

ARTICLE2: EXAMINATIONANDPROCUREMENTOFPROPOSALDOCUMENTS

2.01 AdvertisementandinformationfortheProjectcanbefoundatthefollowingwebsite:

http://www.alamoheightstx.gov/rfp

2.02 Bid Documents may be downloaded or viewed free of charge at this website.It is the

downloader’sresponsibilitytodeterminethatacompletesetofdocumentsissubmitted.

2.03 This website may be updated periodically with Addenda, lists of interested parties, reports or

otherinformationrelevanttosubmittingaBid

fortheProject.

2.04 PrintedcopiesoftheBidDocumentsmaybeobtainedfreeofchargeatthefollowingaddresses:

CityofAlamoHeights

CityHall

6116Broadway

AlamoHeights,TX78209

Attn:MarianV.Mendoza

ARTICLE3: QUESTIONSREGARDINGBIDPROCESSORSOLICITATIONDOCUMENTS

3.01 QuestionsconcerningtheSealedBidsshouldbesubmittedtotheCityofAlamoHeights,6116

Broadway,AlamoHeights,Texas78209,Attn:MarianVargasMendoza,phone210‐882‐1508,

fax210‐822‐8197,mmendoza@alamoheightsx.govnolaterthan10:00a.m.onSeptember

27,

2018.



RequestforSealedBid 

CityofAlamoHeightsJudsonNatureTrailBuilding09/12/18

October2018



ARTICLE4: PRE‐BIDCONFERENCE

4.01 Anon‐mandatoryPre‐BidConferencefortheProjectwillbeheldonWednesday,September

19,2018,at10:00a.m.atJudsonNatureTrailsBuilding–246Viesca,AlamoHeights,Texas

78209.

ARTICLE5: BASISOFAWARD

5.01 The City reserves the right

 to reject any or all bids and to waive any or all informalities  in

connectiontherewith.Citydoesnotbinditselftoacceptthelowestbidoranypartthereo f, and

reservestherighttoaskfornewbidsforthewholeorparts.Themereopeningandreadingaloud

of a bid shall not constitute the City's acceptance of the suitability of a bidder or a bid. The

competencyandresponsibilityofthebidderswillbeconsideredinmakinganaward.

5.02 Determination of the low bidder will be based  on the lowest responsible base bid and/or

combination of the

 base bid and alternate bids. Alternates accepted will be considered in

determiningthelowbidder,theOwnerdoesnotobligateitselftoacceptanalternateoralternates

inanyorderlistedunlessotherwisestipulatedelsewhereintheBiddingDocuments.

ARTICLE6: PROPOSALSECURITY

6.01 BiddersmustsubmitanacceptableBid

BondwiththeirProposalasaguaranteethattheBidder

willenterintoacontractfortheProjectwiththeCitywithin15daysofNoticeofAwardofthe

Contract.ThesecuritymustbepayabletoCityofAlamoHeightsintheamountof5percentof

theproposedContractPrice.

ARTICLE7: OTHERCONTRACTREQUIREMENTS

7.01 ContractorsforthisProjectmustpaynolessthantheprevailingwageratesforthearea

establishedbytheOwnerandcomplywithalllaborlawsestablishedbyStateandFederal

statutes.

7.02 PerformanceandPaymentBondsarerequired.

JOHN GRABLE,

FAIA

222 Austin Highway #1

San Antonio, TX 78209

p 210 820 3332 f 210 820 3334 w johngrable.com

A R C H I T E C T S - I N C .

246 Viesca Street

Alamo Heights, TX 78209

Judson Nature Trail Building

09.12.2018

JOHN GRABLE,

FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT ADDRESS

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, TX 78209

222 Austin Highway #1

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTES:

VICINITY MAP

PROJECT DIRECTORY

SHEET INDEX

STORAGE

STAIR, STRINGER

STORM DRAIN

STRUCTURAL

TEXAS ACCESSIBILITY STANDARDS

TELEPHONE

TELEVISION

THICK (NESS)

TONGUE AND GROOVE

TOP OF PLATE

TOP OF STEEL

TOP OF WALL

TREAD, TEMPERED

WATERPROOF

WATER CLOSET

WATER HEATER

WAINSCOT

VERTICAL

UNLESS NOTED OTHERWISE

TYPICAL

WOOD

WITHOUT

WITH

WINDOW

WEST

WELDED WIRE FABRIC

STOR.

STR.

STRUCT.

TAS

TEL.

THK.

T&G

T.O.P.

T.O.S.

T.O.W.

WP.

W/C

WSCT.

VERT.

UNO

TYP.

WD.

W/O

WIN., WIND.

WWF

INCLUDED

INCL.

ID INTERIOR DESIGN

INSUL. INSULATION

INT.

INTERIOR

M.C.

MED.

MECH.

MAX.

MSRY.

LAV.

LAM.

MEDICINE CABINET

MEDIUM

MECHANICAL

MAXIMUM

MASONRY

LAVATORY

LAMINATE

ABV.

ABOVE

A.F.F. ABOVE FINISHED FLOOR

ADJ.

ADJUSTABLE

A/C AIR CONDITIONING

ALT.

ALTERNATE

ALUM. ALUMINUM

A.B.

ANCHOR BOLT

A.J.

ARCHITECTURAL JOINT

ARCH.

ARCHITECT (URAL)

ASPH.

ASPHALT

BOTH SIDES

BOARD

BLOCKING

BLOCK (ING)

BETWEEN

BELOW

BENCH MARK

BEAM

BEARING

B.S.

BD.

BLKG.

BLK. (G)

BTWN.

BEL.

B.M.

BM.

BRG.

CATCH BASIN

CAST IRON

CASEMENT

CABINET

BUILDING

BOTTOM OF DECK

BOTTOM OF BEAM

BOTTOM

BOTH WAYS

C.B.

C.I.

CSMT

CAB.

BLDG.

B.O.D.

B.O.B.

BOT.

B.W.

CIRCLE

CERAMIC TILE

CEMENT PLASTER (PORTLAND)

CEMENT

CEILING

CIR.

C.T., CER.

CPPL.

CEM.

CLG., CEIL.

ANODIZEDANOD.

ADA AMERICANS WITH DISABILITIES ACT

BIT.

BITUMINOUS

B.O.S. BOTTOM OF STEEL

BUILT UP

CIRC. CIRCLULAR, CIRCUMFERENCE

CLR. CLEAR

COL.

COLUMN

COMB. COMBINATION

CONC. CONCRETE

CMU

CONCRETE MASONRY UNIT

CONST. CONSTRUCTION

CONT. CONTINUOUS, CONTINUE

CONTRACTORCTR.

CONTROL JOINT

C.J.

COUNTERTOPCNTR.

DEEP

DEMOLISH, DEMOLITIONDEMO

DETAILDTL.

DIAGONALDIAG.

DIAMETER

DIA.

DIMENSIONDIM.

DOOR

DR.

DOUBLE HUNG

D.H.

DOUBLEDBL.

DOWNSPOUT

DISPENSERDISP.

DRAWERDWR.

DRAWING

DWG.

EAST

ELEC. ELECTRIC (AL)

ELEV. ELEVATION

ELV. ELEVATOR

EXIST. EXISTING

EPS

EQ.

EQUAL

EMERG. EMERGENCY

FINISHED FLOORFIN. FLR.

FINISH (ED)FIN.

FIRE EXTINGUISHER CABINETFEC

EXTERIOR INSULATION FINISH SYSTEME.I.F.S.

EXPANSION JOINTEXP. JT.

EXPOSEDEXP.

EXHAUST

EX.

FOOT (FEET)

FT.

FREEZERFRZR.

FIBERGLASS REINFORCED PANELFRP

FLUORESCENTFLUOR.

FLOOR DRAINFD

FLOOR (ING)FLR.

FIREPLACE

GYPSUM WALL BOARDGYP. BD.

GLASSGL.

GENERAL CONTRACTORG.C.

GALVANIZEDGALV.

GAGE, GAUGE

GA.

FOUNDATIONFOUND.

FOOTING

FTG.

HEIGHTHGT., HT.

HEAVY DUTY

H.D.

HEATING/VENTILATION/AIR CONTITIONINGHVAC

HEADERHDR.

HARDWAREHDWR.

HANDICAPPEDH/C

GYPSUMGYP.

INCANDESCENTINCAND.

HOSE BIBBHB

HORIZONTALHORIZ.

HOLLOW METAL

HOLLOW COREHC

HIGH

IN. INCHES

STL.

STD.

SQ.

SPEC.

SP.

SIM.

SHLV.

SHT.

SEC., SECT.

SCHED.

REQ'D

RAG

REFG.

PNL.

PLAS.

NTS

PSI

PROP.

REF.

REFL.

PTD.

PANEL

PERF.

P. LAM.

PL.

PLYWD.

PVC

POLYISO

MIN.

MISC.

NOM.

NIC

OPG.

OPP.

MEMB.

MBR.

STEEL

STANDARD

STAINLESS STEEL

SQUARE

SPECIFICATION, SPECIFIED

SPACES

SOUTH

SOLID CORE

SIMILAR

SHELVING

SHEET

SECTION

SCHEDULED

ROUGH OPENING

ROOF DRAIN

RIGHT HAND

REQUIRED

RETURN AIR GRILLE

REFRIGERATOR

PANEL

PLASTER

NOT TO SCALE

POUNDS PER SQUARE INCHES

PROPERTY LINE

RADIUS

REFER (ENCE)

REFLECTED

OUTSIDE DIAMETER

PAINTED

ELECTRICAL PANELBOARD

PERFORATED

PLASTIC LAMINATE

PLATE

PLYWOOD

POLYVINYL CHLORIDE

POLYISOCYANURATE BOARD

MINIMUM

MISCELLANEOUS

NOMINAL

NORTH

NOT IN CONTRACT

ON CENTER (S)

OPPOSITE HAND

OPENING

OPPOSITE

METER (S)

MEMBRANE

MEMBER

EXPANDED (EXTRUDED) POLYSTYRENE BOARD

ABBREVIATIONS

1/A501

A500

RM#

ROOM

A600

A900

A400

DR#

INTERIOR ELEV. NUMBER

DRAWING SYMBOLS

DOOR NUMBER

WINDOW NUMBER

ELEVATION MARK

REVISION NUMBER

ROOM NAME

DETAIL KEY

DETAIL NO.

WALL TYPE

SHEET NO.

HT. ABOVE REF. ELEV. (0'-0")

ROOM NO.

INT. ELEV. NO.

SHEET NO.

EXTERIOR ELEV. NO.

SECTION NO.

SHEET NO.

CLIENT INFO:

ARCHITECT INFO:

BUILDER INFO:

STRUCTURALENGINEER INFO:

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or

disclosed without the

written consent of the

architect

John Grable Architects

222 Austin Highway #1

San Antonio, TX 78209

p. 210.821.3332 e. info@johngrable.com

www.johngrable.com

---

Beiker Engineering

2702 TX 1604 Loop

San Antonio, TX 78232

City of Alamo Heights

6116 Broadway St

Alamo Heights, TX 78209

____ COVER SHEET 09/11/18

A000 INDEX SHEET 09/11/18

A001 SPECIFICATIONS 09/11/18

A002 SPECIFICATIONS 09/11/18

A003 FLOOR PLAN - CUT AWAY 05/29/18

A004 FLOOR PLAN - CUT AWAY 09/09/18

A005 FLOOR PLAN - CUT AWAY 05/29/18

A100 SITE PLAN - AS BUILT 09/11/18

A101 SITE PLAN - PROPOSED 09/11/18

A200 FLOOR PLAN - AS BUILT 09/11/18

A201 FLOOR PLAN - PROPOSED 09/09/18

A202 FLOOR PLAN - PROPOSED 09/11/18

A220 ENLARGED ARCHITECTURAL FLOOR PLANS 09/11/18

A221 FLOOR PLAN - ACCESSABILITY 09/11/18

A290 DOOR SCHEDULE - PROPOSED 09/04/18

A300 BUILDING SECTIONS - AS BUILT 09/11/18

A301 BUILDING SECTIONS - PROPOSED 09/11/18

A400 EXTERIOR ELEVATION - AS BUILT 09/11/18

A401 EXTERIOR ELEVATION - PROPOSED 09/11/18

A600 DETAILS 09/11/18

A700 INTERIOR ELEVATIONS 09/11/18

A701 INTERIOR ELEVATIONS 09/11/18

A930 FRAMING PLANS - AS BUILT 09/11/18

A931 FRAMING PLANS - PROPOSED 09/11/18

A940 ROOF PLAN - AS BUILT 09/11/18

A941 ROOF PLAN - PROPOSED 09/11/18

D100 DEMOLITION PLAN 09/11/18

E100 RCP & ELECTRICAL - AS BUILT 09/11/18

E101 RCP & ELECTRICAL - PROPOSED 09/11/18

P100 PLUMBING LOCATION PLAN - AS BUILT 09/11/18

P101 PLUMBING LOCATION PLAN - PROPOSED 09/11/18

**ARCHITECTURAL DRAWINGS AND SPECS AS INSTRUMENTS OF SERVICE ARE AND SHALL REMAIN EXCLUSIVE PROPERTY OF THE ARCHITECT WHETHER THE PROJECT FOR WHICH THEY ARE

MADE IS EXECUTED OR NOT. ALL DRAWINGS AND WRITTEN MATERIAL APPEARING HEARIN CONSTITUTE ORIGINAL UPUBLISHED WORK OF THE ARCHITECT AND MAY NOT BE DUPLICATED, USED

BY THE OWNER ON OTHER PROJECTS, OR EXTENSIONS TO THIS PROJECT WITHOUT THE WRITTEN CONSENT OF THE ARCHITECT.

ALAMO HEIGHTS

1. THE PROJECT IS COMPLIES THE 2015 INTERNATIONAL CODE SERIES, AS ADOPTED BY THE CITY OF ALAMO HEIGHTS, AND WITH THE CODE OF ORDINANCES OF THE CITY OF ALAMO HEIGHTS.

2. MUST MEET 2012 TAS ACCESSIBILITY STANDARDS.

3. BACKFLOW PREVENTION DEVICES ON INDIVIDUAL PIECES OF EQUIPMENT (AS INDICATED IN TCEQ REGULATIONS), ON FIRE SPRINKLER SYSTEM (IF NEWLY INSTALLED OR UPGRADED

SYSTEM), AND ON WATER SERVICE FROM CITY MAIN.”

4. VACUUM BREAKER DEVICES SHALL BE INSTALLED ON ALL EXTERIOR HOSE BIBS.

5. PROPERTIES FRONTING ALONG BROADWAY AND/OR AUSTIN HIGHWAY SHALL INSTALL SIDEWALKS CONSTRUCTED PER THE CITY OF SAN ANTONIO FLATWORK CONSTRUCTION HANDBOOK

AND SHALL BE ADA COMPLIANT REGARDING SLOPES AND RAMPS.

6. FIRELINES TO FIRE HYDRANTS AND/OR FIRE PROTECTION SPRINKLER SYSTEMS, SHALL BE TAPPED INDEPENDENT OF DOMESTIC WATER LINE.

7. WATER METER INSTALLATIONS SHALL BE IN ACCORDANCE WITH SAN ANTONIO WATER SYSTEM STANDARDS.

ELECTRICAL NOTES

THE ELECTRICAL CONTRACTOR SHALL PROVIDE A FULLY ENGINEERED SYSTEM TO INCLUDE ANY AND ALL REQUIRED DESIGN DOCUMENTS, PROFESSIONAL SEAL, USER DIAGRAMS AND

MATERIAL LIST AS REQUIRED BY THE LOCAL GOVERNING AUTHORITY.

THE ELECTRICAL CONTRACTOR SHALL COORDINATE HIS WORK WITH THE WORK OF OTHER TRADES AND HAVE HIS WORK SCHEDULED SO AS NOT TO DELAY THE WORK OF OTHERS.

THE CONTRACTOR SHALL BE RESPONSIBLE FOR INSPECTION AND APPROVAL OF WIRING, INSTALLATION OF FIXTURES AND EQUIPMENT, AND FOR FINAL ACCEPTANCE OF THE

COMPLETE ELECTRICAL INSTALLATIONS BY THE UNDERWRITER’S OR BY LOCAL ELECTRICAL INSPECTORS.

SERVICE ENTRANCE CONDUCTORS AND EQUIPMENT SHALL BE OF CAPACITY ADEQUATE TO SERVE THE CALCULATED LOAD AND SPARE CIRCUITS PROVIDED FOR FUTURE USE.

1. THE SIZE OF SERVICE ENTRANCE CONDUCTORS AND CAPACITY OF SERVICE EQUIPMENT SHALL BE COMPUTED BY METHOD INDICATED IN THE NATIONAL ELECTRIC CODE.

ELECTRICAL SUBCONTRACTOR TO CALCULATE ALL LOADS AS REQUIRED FOR METER LOOP.

CONFIRM ALL APPLIANCE VENTILATION, ELECTRICAL AND PLUMBING REQUIREMENTS WITH MANUFACTURERS SPECIFICATIONS PRIOR TO STUB OUT FOR CONNECTIONS.

CONFIRM ALL UNDER CABINET LIGHT FIXTURE SELECTIONS, AVAILABLE LENGTHS, AND CONFIRM ALL STUB OUT LOCATIONS FOR UNDER CABINET LIGHTING WITH OWNER PRIOR TO

INSTALLATION.

CONFIRM ALL STUB OUT LOCATIONS FOR BACK SPLASH, WALL SCONCE, BATH FIXTURES AND OUTLET LOCATIONS WITH OWNER PRIOR TO INSTALLATION.

PROVIDE ARC FAULT CIRCUIT INTERRUPTION AT THE KITCHEN AND BATH ROOMS.

OWNER’S VENDOR TO PROVIDE CONTROLS TO ALL THERMOSTATS AND EXTERIOR LIGHTING SYSTEMS.

SMOKE DETECTORS SHALL BE ELECTRONICALLY HARDWIRED WITH A BATTERY BACK UP. ALL SMOKE DETECTORS SHALL BE INTERCONNECTED SO THAT IF ONE OF THE UNITS GOES INTO

ALARM, ALL THE UNITS GO INTO ALARM.

PROVIDE 10-YEAR BACKUP BATTERIES ON SMOKE DETECTORS.

PROVIDE 22OV. POWER AT EACH WATER HEATER LOCATION.

PLUMBING NOTES

PROVIDE AND INSTALL FIXTURES AS NOTED ON THE DRAWINGS.

PROVIDE ALL ACCESSORIES, STRAPS, INSULATION AND OTHER MATERIALS REQUIRED FOR COMPLETE INSTALLATION.

FURNISH AND INSTALL A COMPLETE SYSTEM OF SANITARY DRAINAGE, AND VENTING FOR THE PROJECT INCLUDING EXCAVATION, BACKFILL, DRAINAGE LINES, VENTS, VENT STACKS,

RAINWATER CONDUCTORS, BOOTS, TRAPS, ALL NECESSARY CONNECTIONS TO A PUBLIC SEWER LINE OR INDIVIDUAL WASTER DISPOSAL SYSTEM.

FURNISH AND INSTALL A COMPLETE WATER SUPPLY SYSTEM FOR THE PROJECT INCLUDING WATER SERVICE CONNECTION, PIPE LINES, DRAINS, FITTINGS, CONNECTIONS TO PLUMBING

FIXTURES, AND ALL NECESSARY ACCESSORIES TO PROVIDE A COMPLETE WORKABLE INSTALLATION.

FURNISH AND INSTALL A COMPLETE SYSTEM OF GAS SUPPLY INCLUDING PIPING, CONNECTIONS TO THE GAS COMPANY TAP, CONNECTIONS TO ALL GAS-FIRED EQUIPMENT WITH ALL

NECESSARY VALVES, COCKS, AND OTHER ACCESSORIES NEEDED FOR A COMPLETE INSTALLATION.

GAS PIPING SHALL BE BLACK STEEL PIPE INSTALLED IN COMPLIANCE WITH NFPA REQUIREMENTS.

PROVIDE POWER FOR IRRIGATION CONTROLLER. IRRIGATION SYSTEM TO BE SUPPLIED BY OWNER’S VENDOR UNDER SEPARATE CONTRACT.

ADA/TAS

THE GENERAL CONTRACTOR AND ALL SUB-CONTRACTORS SHALL BE RESPONSIBLE FOR THE ENFORCEMENT OF ALL REQUIREMENTS AND REGULATIONS AND SHALL PERFORM ALL

WORK ON THIS PROJECT IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT.

INFORMATION SHOWN ON THIS SHEET IS MINIMUM REQUIRED FOR ADA COMPLIANCE

ALL CONDITIONS SHOWN ON THIS SHEET MAY NOT BE REQUIRED BY THIS PROJECT. COMPARE THE REQUIREMENTS OF THE ARCHITECTURAL DRAWINGS WITH THIS SHEET FOR

RELEVANCE OF INFORMATION.

NOTIFY THE ARCHITECT IMMEDIATELY OF ANY DISCREPANCY BETWEEN THE ARCHITECTURAL DRAWINGS AND INFORMATION GIVEN ON THIS SHEET FOR CLARIFICATION.

JOHN GRABLE,

FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A001

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A002

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A003

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

FLOOR PLAN CUT AWAY - AS BUILT

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A004

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

FLOOR PLAN CUT AWAY - PROPOSED BASE BID

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A005

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

FLOOR PLAN CUT AWAY - PROPOSED ALTERNATE BID

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A100

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1" = 30'-0"

SITE PLAN - AS BUILT

15'

SCALE 1:30

150'100'50'

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A101

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1" = 30'-0"

SITE PLAN - PROPOSED

15'

SCALE 1:30

150'100'50'

A300

A400

7' - 0 7/8" 10' - 0" 7' - 0 7/8"

10' - 0"

7' - 0 7/8" 10' - 0" 7' - 0 7/8"

2' - 2 3/16"

2' - 8 1/2" 2' - 2 1/8" 3' - 1" 3' - 10" 3' - 1" 2' - 2 3/16"

2' - 8 1/2" 2' - 2 1/8"

7' - 0 7/8" 10' - 0" 7' - 0 7/8"

10' - 0" 2' - 2 3/16" 2' - 8 1/2" 2' - 2 1/8"

7' - 0 7/8" 10' - 0" 7' - 0 7/8"

2' - 2 1/8" 2' - 8 1/2" 2' - 2 3/16"

4' - 4 1/2" 0' - 8" 3' - 6" 0' - 8" 2' - 7" 1' - 6"

4' - 2"

13' - 4 1/2"

11' - 4 1/2"

1' - 9 3/4"1' - 10"1' - 7 3/4"2' - 1"4' - 0"

10' - 5 3/16"

3' - 8 1/2" 0' - 8" 2' - 8 1/4" 0' - 8" 2' - 8 7/16"

11' - 1"

1' - 7" 5' - 4 1/2" 4' - 1 1/2"

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A200

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

FLOOR PLAN - AS BUILT

SCALE 1/4"

10' 20'

1' 5'

6' - 7" 4' - 6"

11' - 1"

4' - 1 11/16" 6' - 7"

10' - 8 11/16"

6' - 7" 5' - 3 1/2"

11' - 10 1/2"

10' - 5 3/16" 7' - 5" 4' - 7 1/2"

22' - 5 11/16"

5' - 3 1/2"6' - 1"

6' - 7"4' - 9 1/2"

11' - 4 1/2"

- 11 3/8"

3' - 10 3/16"6' - 7"

10' - 5 3/16"

11' - 4 1/2"

3' - 4 3/16" 6' - 7"

1' - 6" 8' - 5 3/16"

9' - 11 3/16"

94 SF

ADA SINGLE-OCCUPANCY

BATHROOM

123 SF

SINGLE-OCCUPANCY BATHROOM

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A201

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

FLOOR PLAN - PROPOSED BASE BID

SCALE 1/4"

10' 20'1' 5'

A401

A301

123 SF

WOMENS BATHROOM

94 SF

MENS BATHROOM

177 SF

STORAGE

6' - 7" 4' - 6"

11' - 1"

4' - 1 11/16" 6' - 7"

10' - 8 11/16"

6' - 7" 5' - 3 1/2"

11' - 10 1/2"

10' - 5 3/16" 7' - 5" 4' - 7 1/2"

22' - 5 11/16"

5' - 3 1/2"6' - 1"

6' - 7"4' - 9 1/2"

11' - 4 1/2"

- 11 3/8"

3' - 10 3/16"6' - 7"

10' - 5 3/16"

11' - 4 1/2"

3' - 4 3/16" 6' - 7"

1' - 6" 8' - 5 3/16"

9' - 11 3/16"

A700

A701

A301

A701

11 12

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A202

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

FLOOR PLAN - PROPOSED ALTERNATE BID

SCALE 1/4"

10' 20'1' 5'

A301

A600

LAVATORY

3' - 5" 0' - 1"

URINAL

2' - 6 1/2" 0' - 0 1/2"

STALL

5' - 0"

FACE of WALL

11' - 1"

0' - 4"

DOOR / CURTAIN

2' - 8" 2' - 0"

A700

5' - 2 1/2" 0' - 3"

DOOR

2' - 8" 0' - 2" 0' - 5"

DOOR

2' - 8" 2' - 0"

FACE OF WALL

13' - 4 1/2"

A701

A301

5' - 2 1/2" 0' - 1"

STALL

3' - 0" 0' - 1"

STALL

5' - 0"

A701

11 12

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A220

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/2" = 1'-0"

ENLARGED FLOOR PLAN

SCALE 1/2"

6' 10'1' 3'

A301

- 5 3/4

- 5 3/16"

59"x60"

WHEELCHAIR

ACCESSIBLE

30"x48"

URINAL

30"x48"

LAVITORY

30"x48"

CHANGING

STATION

30"x48"

CHANGING

STATION

30"x48"

LAVITORY

60"x60"

WHEELCHAIR

ACCESSIBLE

36"x60"

AMBULATORY

ACCESSIBLE

48"x48"

DOOR

48"x48"

DOOR

A301

ø 5' - 0"

0' - 4" 2' - 8" 2' - 0"

5' - 0"

18" x 18"

SIGN

18" x 18"

SIGN

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A221

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/2" = 1'-0"

ACCESSABLILITY PLAN - PROPOSED - PHASE ONE

SCALE 1/2"

6' 10'1' 3'

FIN FLR

R.O. WIDTH

3' - 0 1/2"

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A290

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

DOOR SCHEDULE

MARK TYPE

SIZE

MANUFACTURER

DOOR

FRAME MATERIAL

DOOR and FRAME

FINISH

DETAILS

COMMENTS MARK

R.O.

WIDTH

R.O.

HEIGHT

DOOR MATERIAL

DOOR

THICKNESS

HEAD JAMB THRESHOLD

10 A 3' - 0 1/2" 7' - 1 1/4" ASSA ABLOY 707 SERIES HOLLOW METAL DOOR 0' - 1 3/4" FLUSH KD FACE FRAME PAINT per SPECs A600-1 A600-2 A600-3 MUST MEET TAS 2012 STANDARDS 10

11 A 3' - 0 1/2" 7' - 1 1/4" ASSA ABLOY 707 SERIES HOLLOW METAL DOOR 0' - 1 3/4" FLUSH KD FACE FRAME PAINT per SPECs A600-1 A600-2 A600-3 MUST MEET TAS 2012 STANDARDS 11

12 A 3' - 0 1/2" 7' - 1 1/4" ASSA ABLOY 707 SERIES HOLLOW METAL DOOR 0' - 1 3/4" FLUSH KD FACE FRAME PAINT per SPECs A600-1 A600-2 A600-3 MUST MEET TAS 2012 STANDARDS 12

SCALE :

1/2" = 1'-0"

DOOR TYPES

SCALE 1/2"

6' 10'1' 3'

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

A600

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING 3x6 STRUCTURAL T&G WOOD

DECK TO BE REPLACED

EXISTING METAL ROOF TO BE REPLACED

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

EXISTING METAL ROOF and PLYWOOD

DECK TO BE REPLACED

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING 3x6 STRUCTURAL T&G WOOD

DECK TO BE REPLACED

EXISTING METAL ROOF TO BE REPLACED

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

EXISTING METAL ROOF and PLYWOOD

DECK TO BE REPLACED

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

EXISTING METAL ROOF TO BE REPLACED

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING 3x6 STRUCTURAL T&G WOOD

DECK TO BE REPLACED

EXISTING METAL ROOF TO BE REPLACED

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A300

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

SECTION through MENS BATHROOM - AS BUILT

SCALE :

1/4" = 1'-0"

SECTION through MENS and WOMENS BATHROOM - AS BUILT

SCALE :

1/4" = 1'-0"

SECTION through WOMENS and MENS BATHROOM - AS BUILT

SCALE 1/4"

10' 20'1' 5'

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

NEW 3/4" PLYWOOD ROOF DECK OVER

EXISTING FRAMING

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

CUSTOM STEEL 'LANTERN' with HOT-DIP

GALVANIZED FINISH. SEE SHEET A600

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

NEW 3/4" PLYWOOD ROOF DECK OVER

EXISTING FRAMING

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

CUSTOM STEEL 'LANTERN' with HOT-DIP

GALVANIZED FINISH. SEE SHEET A600

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

NEW 3/4" PLYWOOD ROOF DECK OVER

EXISTING FRAMING

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

A941

EXISTING WINDOW TO REMAIN. CLEAN and

RE-PAINT per SPECIFICATIONS TYP.

EXISTING DISPLAY CASE TO REMAIN.

CLEAN and RE-PAINT per SPECIFICATIONS

TYP.

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A301

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

SECTION through WOMENS and MENS BATHROOM - PROPOSED

SCALE :

1/4" = 1'-0"

SECTION through MENS and WOMENS BATHROOM - PROPOSED

SCALE 1/4"

10' 20'1' 5'

SCALE :

1/4" = 1'-0"

SECTION through MENS BATHROOM - PROPOSED

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING METAL ROOF and 3x6

STRUCTURAL T&G WOOD DECK TO BE

REPLACED

EXISTING METAL ROOF and PLYWOOD

DECK TO BE REPLACED

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

T.O.W.

9' - 10"

A300

FINISH FLOOR

0' - 0"

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING METAL ROOF and 3x6

STRUCTURAL T&G WOOD DECK TO BE

REPLACED

EXISTING METAL ROOF and PLYWOOD

DECK TO BE REPLACED

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A400

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

NORTH ELEVATION - AS BUILT

SCALE :

1/4" = 1'-0"

EAST ELEVATION - AS BUILT

SCALE 1/4"

10' 20'1' 5'

SCALE :

1/4" = 1'-0"

SOUTH ELEVATION - AS BUILT

SCALE :

1/4" = 1'-0"

WEST ELEVATION - AS BUILT

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

EXISTING DISPLAY CASE TO REMAIN.

CLEAN and RE-PAINT per SPECIFICATIONS

TYP.

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

EXISTING DISPLAY CASE TO REMAIN.

CLEAN and RE-PAINT per SPECIFICATIONS

TYP.

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

EXISTING WINDOW TO REMAIN. CLEAN and

RE-PAINT per SPECIFICATIONS TYP.

PROVIDE BATHROOM SIGN With

PICTOGRAM and BRAILLE to COMPLY per

TAS STANDARD 703 TYP.

CUSTOM STEEL 'LANTERN' with HOT-DIP

GALVANIZED FINISH. SEE SHEET A600

A600

T.O.W.

9' - 10"

FINISH FLOOR

0' - 0"

A301

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

EXISTING 3x3 HSS STEEL COLUMN TO

REMAIN TYP.

EXISTING EXTERIOR BRICK WALLS TO

REMAIN TYP.

EXISTING WINDOW TO REMAIN. CLEAN and

RE-PAINT per SPECIFICATIONS TYP.

PROVIDE BATHROOM SIGN With

PICTOGRAM and BRAILLE to COMPLY per

TAS STANDARD 703 TYP.

CUSTOM STEEL 'LANTERN' with HOT-DIP

GALVANIZED FINISH. SEE SHEET A600

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A401

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

EAST ELEVATION - PROPOSED

SCALE :

1/4" = 1'-0"

NORTH ELEVATION - PROPOSED

SCALE 1/4"

10' 20'1' 5'

SCALE :

1/4" = 1'-0"

SOUTH ELEVATION - PROPOSED

SCALE :

1/4" = 1'-0"

WEST ELEVATION - PROPOSED

(

)

JAMB

STOP

0' - 0 1/2"

MASONRY WALL

0' - 10" 0' - 0 1/2"

0' - 0 1/2"

MASONRY WALL

0' - 10" 0' - 0 1/2"

JAMB DEPTH

0' - 11"

(

)

JAMB DEPTH

0' - 11"

INTERIOR

EXTERIOR

(3) McKINNEY STANDARD WEIGHT SPRING

HINGE 1553-TRS TYP.

707 SERIES COMPOSITE 1 3/4" HOLLOW

METAL DOOR with POLYSTYRENE

INSULATED CORE. PAINT per

SPECIFICATIONS TYP.

FLUSH KD M SERIES NARROW FACE

FRAME 14 GAUGE COLD-ROLLED STEEL.

ARC. WELD MITERED CORNERS and

GRIND SMOOTH. PAINT per

SPECIFICATIONS TYP.

SHIM + JAMBSHIM + JAMB

0' - 0 3/8"

ROCKWOOD RM3300 STRAIGHT PULL, 24"

CTC 30" OVERALL LENGTH with US32D

SATIN STAINLESS STEEL FINISH

707 SERIES COMPOSITE 1 3/4" HOLLOW

METAL DOOR with POLYSTYRENE

INSULATED CORE. PAINT per

SPECIFICATIONS TYP.

FLUSH KD M SERIES NARROW FACE

FRAME 14 GAUGE COLD-ROLLED STEEL.

ARC. WELD MITERED CORNERS and

GRIND SMOOTH. PAINT per

SPECIFICATIONS TYP.

FINISH FLOOR

0' - 0"

707 SERIES COMPOSITE 1 3/4" HOLLOW

METAL DOOR with POLYSTYRENE

INSULATED CORE. PAINT per

SPECIFICATIONS TYP.

PEMKO 2009_A_PK DOOR THRESHOLD with

MILL FINISH ALUMINUM FINSIH and

PEMKOPRENE INSERT TYP.

A600

1/2 STEEL CAP PLATE with GALVANIZED

FINISH per SPECIFICATIONS

(8) 1/4" SAFTY GLASS PANEL with FROSTED

WHITE FILM at INTERIOR OF 'LANTERN'

1/4" SQUARE STEEL ROD 'MULLION' BAR /

GLASS STOP with GALVANIZED FINISH per

SPECIFICATIONS

(8) L 1x1x1/8 STEEL ANGLE FRAME. MITER

CORNERS WELD and GRIND SMOOTH.

GALVANIZED FINISH per SPECIFICATIONS

24 GA. GALVANIZED BREAK METAL DRIP

EDGE. PROVIDE VERTICAL LEG at

INTERIOR of LANTERN

A600

1/2 STEEL CAP PLATE ABOVE SHOWN

DASHED

SET 1/4" SAFTY GLASS PANEL with

CONTINOUS BEAD of STRUCTURAL

SILICONE ALONG ALL FOUR SIDES of

STEEL ANGLE FRAME

1/4" SQUARE STEEL ROD 'MULLION' BAR /

GLASS STOP with GALVANIZED FINISH per

SPECIFICATIONS

(8) L 1x1x1/8 STEEL ANGLE FRAME. MITER

CORNERS WELD and GRIND SMOOTH.

GALVANIZED FINISH per SPECIFICATIONS

(8) 1/4" SAFTY GLASS PANEL with FROSTED

WHITE FILM at INTERIOR OF 'LANTERN'

CONTINOUS WELD at INTERSECTION of

STEEL ANGLE FRAME TYP.

A600

1/2 STEEL CAP PLATE with GALVANIZED

FINISH per SPECIFICATIONS

SET 1/4" SAFTY GLASS PANEL with

CONTINOUS BEAD of STRUCTURAL

SILICONE ALONG ALL FOUR SIDES of

STEEL ANGLE FRAME

1/4" SQUARE STEEL ROD 'MULLION' BAR /

GLASS STOP with GALVANIZED FINISH per

SPECIFICATIONS

(8) L 1x1x1/8 STEEL ANGLE FRAME. MITER

CORNERS WELD and GRIND SMOOTH.

GALVANIZED FINISH per SPECIFICATIONS

24 GA. GALVANIZED BREAK METAL DRIP

EDGE. PROVIDE VERTICAL LEG at

INTERIOR of LANTERN

CAP PLATE

2' - 0"

0' - 3" 1' - 6" 0' - 3"

(8) 1/4" SAFTY GLASS PANEL with FROSTED

WHITE FILM at INTERIOR OF 'LANTERN'

0' - 1" VERTICAL LEG

0' - 1"

DRIP

EDGE

FLASHING

NEW 2x8 BLOCKING BETWEEN EXISITNG

RAFTER MEMBERS

SECURE LANTERN with 1/4" STEEL STRAP

and GALVANIZED SCREWS THROUGH

STEEL ANGLE FRAME and 2x8 BLOCKING

1" SQUARE BAR WELDED TO CAP PLATE.

SECURE (4) LED TAPE LIGHT at EACH

FACE SHOWN DASHED

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A600

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

3" = 1'-0"

EXTERIOR DOOR DETAIL - JAMB TYP.

SCALE :

3" = 1'-0"

EXTERIOR DOOR DETAIL - HEAD TYP.

SCALE :

3" = 1'-0"

EXTERIOR DOOR DETAIL - THRESHOLD TYP.

SCALE 3"

4" 2'

SCALE :

1 1/2" = 1'-0"

CUSTOM LANTERN - ELEVATION

SCALE :

1 1/2" = 1'-0"

CUSTOM LANTERN - PLAN DETAIL

SCALE :

1 1/2" = 1'-0"

CUSTOM LANTERN - SECTION DETAIL

3' - 7"

TOILET

1' - 5"

STALL

5' - 0"

0' - 5 15/16"3' - 0" GRAB BAR1' - 6 1/16"

NEW TOILET as SCHEDULED. REMOVE

EXISTING BRICK as REQUIRED FOR NEW

PLUMBING, and RE-POINT BRICK SAVED

FROM DEMOLITION

NEW 1 1/4" O.D. STANLESS STEEL GRAB

BARs per TAS STANDARDS 609

(

)

FINISH FLOOR

0' - 0"

0' - 11 15/16"

GRAB BAR

3' - 6" 0' - 5 1/16" 2' - 2 3/16"

STALL

4' - 11" 0' - 1" 5' - 5 3/16"

10' - 5 3/16"

MIN.

0' - 7"

NEW TOILET PAPER DISPENSER per TAS

STANDARS 309.4 with 7" MIN. CLEARANCE

from TOILET

NEW BABY CHANGING STATION as

SCHEDULED

FINISH FLOOR

0' - 0"

5' - 0 7/8"2' - 6"0' - 1"3' - 5"

0' - 5"

CURTAIN DOOR

3' - 3" 1' - 4 7/8"

11' - 0 7/8"

NEW URINAL as SCHEDULED per TAS 605.

REMOVE EXISTING BRICK as REQUIRED

FOR NEW PLUMBING, and RE-POINT BRICK

SAVED FROM DEMOLITION

NEW LAVATORY as SCHEDULED per TAS

STANDARS 606

NEW HAND DRIER as SCHEDULED

NEW SOAP DISPENSER as SCHEDULED per

TAS STANDARD

NEW MIRROR per TAS STANDARS 603.3

EXISTING WALL SCONCE to be REUSED at

NEW LOCATION. PROVIDE LED RETROFIT

BULB.

NEW BABY CHANGING STATION as

SCHEDULED

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A700

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

MENs BATHROOM - AXON VIEW

SCALE :

1/2" = 1'-0"

MENS - STALL NORTH

SCALE :

1/2" = 1'-0"

MENS - EAST

SCALE :

1/2" = 1'-0"

MENS - NORTH

SCALE 1/2"

6' 10'1' 3'

0' - 4 9/16"

GRAB BAR

3' - 6" 1' - 1 7/16"

11' - 4 1/2"

1' - 9" 3' - 6 1/2" 1' - 0" 0' - 1"

STALL

5' - 0"

NEW TOILET as SCHEDULED. REMOVE

EXISTING BRICK as REQUIRED FOR NEW

PLUMBING, and RE-POINT BRICK SAVED

FROM DEMOLITION

NEW 1 1/4" O.D. STANLESS STEEL GRAB

BARs per TAS STANDARDS 609

NEW TOILET PAPER DISPENSER per TAS

STANDARS 309.4 with 7" MIN. CLEARANCE

from TOILET

EXISTING WALL SCONCE to be REUSED at

NEW LOCATION. PROVIDE LED RETROFIT

BULB.

LAVATORY

FINISH FLOOR

0' - 0"

5' - 3 1/2"

2' - 1 1/2" 3' - 2"

NEW LAVATORY as SCHEDULED per TAS

STANDARS 606

NEW HAND DRIER as SCHEDULED

NEW SOAP DISPENSER as SCHEDULED per

TAS STANDARD

NEW MIRROR per TAS STANDARS 603.3

FINISH FLOOR

0' - 0"

FINISH FLOOR

0' - 0"

0' - 1"

STALL

3' - 0"0' - 1"

WHEELSTAIR STALL

5' - 0"

1' - 6 1/2"1' - 5 1/2"1' - 6 1/16"

GRAB BAR

3' - 0"0' - 5 15/16"

TOILET

5' - 0"

TOILET

NEW 1 1/4" O.D. STANLESS STEEL GRAB

BARs per TAS STANDARDS 609

NEW TOILET as SCHEDULED. REMOVE

EXISTING BRICK as REQUIRED FOR NEW

PLUMBING, and RE-POINT BRICK SAVED

FROM DEMOLITION

NEW BABY CHANGING STATION as

SCHEDULED

(

)

FINISH FLOOR

0' - 0"

MIN.

0' - 7"

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A701

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

WOMENs BATHROOM - AXON VIEW

SCALE :

1/2" = 1'-0"

WOMENS - EAST

SCALE :

1/2" = 1'-0"

WOMENS - NORTH

SCALE :

1/2" = 1'-0"

WOMENS - SOUTH

SCALE 1/2"

6' 10'1' 3'

SCALE :

1/2" = 1'-0"

WOMENS - STALL EAST

A300

EXISTING 3x6 STRUCTURAL T&G WOOD

DECK TO BE REPLACED

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

MAX T&G DECK SPAN

18' - 7 15/16"

MIN. T&G DECK SPAN

10' - 0"

EXISTING METAL ROOF TO BE REPLACED

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A930

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

ROOF FRAMING PLAN - AS BUILT

SCALE 1/4"

10' 20'1' 5'

A301

EXISTING 2x4 and 2x6 RAFTER FRAMING

TO REMAIN, FEILD VERIFY STRUCTURAL

INTEGRITY

EXISTING 2x12 BEAMS TO REMAIN, FEILD

VERIFY STRUCTURAL INTEGRITY

EXISTING DOUBLE 2x12 BEAM TO REMAIN,

FIELD VERIFY STRUCTURAL INTEGRITY

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 3/4" PLYWOOD ROOF DECK OVER

EXISTING FRAMING

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A931

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

ROOF FRAMING PLAN - PHASE ONE

SCALE 1/4"

10' 20'1' 5'

EXISTING METAL ROOF and 3x6

STRUCTURAL T&G WOOD DECK TO BE

REPLACED

EXISTING METAL ROOF and PLYWOOD

DECK TO BE REPLACED

6" / 12"

3" / 12"

TRANSITION

TRA

TION

TRA

TION

TRANS

TION

TRANS

TION

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A940

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

ROOF PLAN - AS BUILT

SCALE 1/4"

10' 20'1' 5'

A301

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

2" DRIP EDGE

3" / 12" 6" / 12" 6" / 12" 3" / 12"

2" DRIP EDGE

RIP

2" DRIP EDGE

RIP

TRANSITION

TRA

TION

TRA

TION

TRANS

TION

TRANS

TION

A941

SIM

CONTINOUS ICE and SNOW SHEILD

BELOW NEW STANDING SEAM METAL

ROOF TYP.

NEW 24 GA. GALVANIZED BREAK METAL

DRIP EDGE at ALL EAVES TYP.

NEW 5x6 'LOCK-DECK' LAMINATED

STRUCTURAL DECK

NEW 26 GAUAGE G90 GALVANIZED

STANDING SEAM METAL ROOF with

DOUBLE-LOCK SEAMS and RIDGES TYP.

NEW 24 GA. GALVANIZED BREAK METAL

DRIP EDGE at ALL EAVES TYP.

CONTINOUS ICE and SNOW SHEILD

BELOW NEW STANDING SEAM METAL

ROOF TYP.

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

A941

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

ROOF PLAN - PROPOSED - PHASE ONE

SCALE 1/4"

10' 20'1' 5'

SCALE :

1 1/2" = 1'-0"

ROOF EAVE DETAIL TYP.

SCALE 1 1/2"

3'1'

A301

13' - 4 1/2"

11' - 1"

REMOVE CLEAN and STORE BRICK FROM

DEMOLITION at PARTITION WALL FOR USE

in RENOVATION TYP.

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

D100

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/2" = 1'-0"

DEMOLITION PLAN

SCALE 1/2"

6' 10'1' 3'

A300

A400

EXISTING LIGHT FIXTURE to be

RELOCATED

EXISTING LIGHT FIXTURE to be

RELOCATED

EXISTING LIGHT FIXTURE to REMAIN

EXISTING SPRINKLER CONTROL to

REMAIN

EXISTING ELECTRICAL BREAKER PANEL to

be REPLACED

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

E100

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

RCP AND ELECTRICAL PLAN - AS BUILT

SCALE 1/4"

10' 20'1' 5'

A301

55"

39"

EXISTING LIGHT FIXTURE to REMAIN

55"

NEW LED TAPE LIGHT at EXISTING LIGHT

FIXTURE LOCATION

NEW LED TAPE LIGHT at EXISTING

DISPLAY BOX TYP.

EXISTING LIGHT FIXTURE to be

RELOCATED

EXISTING LIGHT FIXTURE to be

RELOCATED

PROVIDE NEW ELECTRICAL BREAKER

PANEL

TO CUSTOM 'LANTERN' at ROOF PEAK

LABEL/SYMBOL

MANUFACTURER

MODEL

LIGHT FIXTURE SCHEDULE

COMMENTS

BROAN L150MG

POWER SUPPLY

EXISTING FIXTURE to be REMAIN--- ------

LED-TO2427-5-WT ---EN-OD24100-RB2-T

55"

39"

------

EXISTING FIXTURE to be RELOCATED

--- --- ---

LED-T2427L-5-WT ---EN-2460-RB2-T

TYPE

WALL SCONCE

CEILING SCONCE

RECESSED EXAUST FAN

TAPE LIGHT

WAC

---CUSTOM 'LANTERN' SEE SHEET A600 for DETAILSWAC ---(x4) LED-TO2427-5-WT EN-OD24100-RB2-T

ACCESSORIES

---

LED-TO24-CH5

(x4) LED-TO24-CH5

NOTE: FIELD VERIFY TRANSFORMER LOCATION with ARCHITECT / OWNER

LED-TO24-CH5

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

E101

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

RCP AND ELECTRICAL PLAN - PHASE ONE

SCALE 1/4"

10' 20'1' 5'

ELECTRICAL NOTES

1. THE ELECTRICAL CONTRACTOR SHALL PROVIDE A FULLY ENGINEERED SYSTEM TO INCLUDE ANY AND ALL REQUIRED DESIGN DOCUMENTS, PROFESSIONAL SEAL,

USER DIAGRAMS AND MATERIAL LIST AS REQUIRED BY THE LOCAL GOVERNING AUTHORITY.

2. THE ELECTRICAL CONTRACTOR SHALL COORDINATE HIS WORK WITH THE WORK OF OTHER TRADES AND HAVE HIS WORK SCHEDULED SO AS NOT TO DELAY THE

WORK OF OTHERS.

3. THE CONTRACTOR SHALL BE RESPONSIBLE FOR INSPECTION AND APPROVAL OF WIRING, INSTALLATION OF FIXTURES AND EQUIPMENT, AND FOR FINAL

ACCEPTANCE OF THE COMPLETE ELECTRICAL INSTALLATIONS BY THE UNDERWRITER’S OR BY LOCAL ELECTRICAL INSPECTORS.

4. SERVICE ENTRANCE CONDUCTORS AND EQUIPMENT SHALL BE OF CAPACITY ADEQUATE TO SERVE THE CALCULATED LOAD AND SPARE CIRCUITS PROVIDED FOR

FUTURE USE.

5. THE SIZE OF SERVICE ENTRANCE CONDUCTORS AND CAPACITY OF SERVICE EQUIPMENT SHALL BE COMPUTED BY METHOD INDICATED IN THE NATIONAL ELECTRIC

CODE.

6. ELECTRICAL SUBCONTRACTOR TO CALCULATE ALL LOADS AS REQUIRED FOR METER LOOP.

7. CONFIRM ALL APPLIANCE VENTILATION, ELECTRICAL AND PLUMBING REQUIREMENTS WITH MANUFACTURERS SPECIFICATIONS PRIOR TO STUB OUT FOR

CONNECTIONS.

8. CONFIRM ALL UNDER CABINET LIGHT FIXTURE SELECTIONS, AVAILABLE LENGTHS, AND CONFIRM ALL STUB OUT LOCATIONS FOR UNDER CABINET LIGHTING WITH

OWNER PRIOR TO INSTALLATION.

9. CONFIRM ALL STUB OUT LOCATIONS FOR BACK SPLASH, WALL SCONCE, BATH FIXTURES AND OUTLET LOCATIONS WITH OWNER PRIOR TO INSTALLATION.

10. PROVIDE ARC FAULT CIRCUIT INTERRUPTION AT THE KITCHEN AND BATH ROOMS.

11. OWNER’S VENDOR TO PROVIDE CONTROLS TO ALL THERMOSTATS AND EXTERIOR LIGHTING SYSTEMS.

12. SMOKE DETECTORS SHALL BE ELECTRONICALLY HARDWIRED WITH A BATTERY BACK UP. ALL SMOKE DETECTORS SHALL BE INTERCONNECTED SO THAT IF ONE OF

THE UNITS GOES INTO ALARM, ALL THE UNITS GO INTO ALARM.

13. PROVIDE 10-YEAR BACKUP BATTERIES ON SMOKE DETECTORS.

14. PROVIDE 22OV. POWER AT EACH WATER HEATER LOCATION.

A300

13' - 4 1/2"

TOILET

6' - 9 1/2" 6' - 7"

URINAL

12' - 6 1/2" 0' - 10"

11' - 1"

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

P100

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

PLUMBING LOCATION PLAN - AS BUILT

SCALE 1/4"

10' 20'1' 5'

PLUMBING NOTES

PROVIDE AND INSTALL FIXTURES AS NOTED ON THE DRAWINGS.

PROVIDE ALL ACCESSORIES, STRAPS, INSULATION AND OTHER MATERIALS REQUIRED FOR COMPLETE INSTALLATION.

FURNISH AND INSTALL A COMPLETE SYSTEM OF SANITARY DRAINAGE, AND VENTING FOR THE PROJECT INCLUDING EXCAVATION, BACKFILL, DRAINAGE LINES, VENTS,

VENT STACKS, RAINWATER CONDUCTORS, BOOTS, TRAPS, ALL NECESSARY CONNECTIONS TO A PUBLIC SEWER LINE OR INDIVIDUAL WASTER DISPOSAL SYSTEM.

FURNISH AND INSTALL A COMPLETE WATER SUPPLY SYSTEM FOR THE PROJECT INCLUDING WATER SERVICE CONNECTION, PIPE LINES, DRAINS, FITTINGS, CONNECTIONS

TO PLUMBING FIXTURES, AND ALL NECESSARY ACCESSORIES TO PROVIDE A COMPLETE WORKABLE INSTALLATION.

FURNISH AND INSTALL A COMPLETE SYSTEM OF GAS SUPPLY INCLUDING PIPING, CONNECTIONS TO THE GAS COMPANY TAP, CONNECTIONS TO ALL GAS-FIRED

EQUIPMENT WITH ALL NECESSARY VALVES, COCKS, AND OTHER ACCESSORIES NEEDED FOR A COMPLETE INSTALLATION.

GAS PIPING SHALL BE BLACK STEEL PIPE INSTALLED IN COMPLIANCE WITH NFPA REQUIREMENTS.

PROVIDE POWER FOR IRRIGATION CONTROLLER. IRRIGATION SYSTEM TO BE SUPPLIED BY OWNER’S VENDOR UNDER SEPARATE CONTRACT.

ADA/TAS

THE GENERAL CONTRACTOR AND ALL SUB-CONTRACTORS SHALL BE RESPONSIBLE FOR THE ENFORCEMENT OF ALL REQUIREMENTS AND REGULATIONS AND SHALL

PERFORM ALL WORK ON THIS PROJECT IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT.

INFORMATION SHOWN ON THIS SHEET IS MINIMUM REQUIRED FOR ADA COMPLIANCE

ALL CONDITIONS SHOWN ON THIS SHEET MAY NOT BE REQUIRED BY THIS PROJECT. COMPARE THE REQUIREMENTS OF THE ARCHITECTURAL DRAWINGS WITH THIS SHEET

FOR RELEVANCE OF INFORMATION.

NOTIFY THE ARCHITECT IMMEDIATELY OF ANY DISCREPANCY BETWEEN THE ARCHITECTURAL DRAWINGS AND INFORMATION GIVEN ON THIS SHEET FOR CLARIFICATION.

PROJECT CLOSEOUT

THE CONTRACTOR SHALL PAY FOR AND OBTAIN FROM THE CITY, MUNICIPALITY, OR OTHER GOVERNING BODY, THE “CERTIFICATE OF OCCUPANCY” AND/OR OTHER

NECESSARY DOCUMENTS FOR THE OWNER TO FULLY OCCUPY AND OPERATE THE COMPLETED PROJECT IN ACCORDANCE WITH ALL APPLICABLE LAWS AND ORDINANCES.

CLEAN-UP: THE CONTRACTOR AT ALL TIMES SHALL KEEP THE PROJECT SITE FREE FROM ACCUMULATION OF WASTE MATERIALS OR RUBBISH CAUSED BY HIS OPERATIONS.

AT THE COMPLETION OF EACH TRADE OF THE WORK, AND AT FINAL COMPLETION, AND NOT LATER THAN SEVEN DAYS BEFORE FINAL PAYMENT, HE SHALL REMOVE ALL HIS

WASTE MATERIALS AND RUBBISH FROM AND ABOUT THE PROJECT AS WELL AS ALL HIS TOOLS, CONSTRUCTION, EQUIPMENT, MACHINERY AND SURPLUS MATERIALS.

A301

11' - 1"

URINAL

4' - 9" 6' - 4"

TOILET

9' - 8" 1' - 5"

TOILET

6' - 10" 6' - 6 1/2"

TOILET

11' - 11 1/2" 1' - 5"

13' - 4 1/2"

P.01

P.01 P.04 P.02 P.05

P.03

P.02 P.02

P.03

MARK

ROOM

ITEM

FITTINGS

MANUFACTURER

COMMENTSCOUNT

PLUMBING FIXTURE & FITTINGS SCHEDULE

MODEL NUMBER

TYPE

WOMENS

MENS

BATHROOM

LAVATORY 2P.01 LAVATORY

HAND DRYER

SOAP DISPENSER

WOMENS

MENS

BATHROOM

TOILET 3P.02

TOILET

TOILET PAPER DISPENSER

WOMENS

MENS

BATHROOM

CHANGING

STATION

2P.03

CHANGING STATION

MENS

BATHROOM

URINAL 1P.04 URINAL

STORAGE

ROOM

SINK 1P.05 SINK

DECOLAV

JOHN GRABLE, FAIA

REVISIONS:

SHEET NO.

CHECKED:

DATE:

APPROVED:

PROJECT INFO

DRAWN:

p 210 820 3332 f 210 820 3334 w johngrable.com

San Antonio, Texas 78209

222 Austin Highway

A R C H I T E C T S - I N C .

ABCDEFGHIJKLM

MLK

IHGFEDCBA

NOTE:

All drawings and written

material appearing herein

constitute original and

unpublished work of the

architect and may not be

duplicated, used or disclosed

without the written consent of

the architect.

09.12.2018

P101

09.12.2018

BID SET

Judson Nature Trail

Building

246 Viesca Street

Alamo Heights, TX 78209

SCALE :

1/4" = 1'-0"

PLUMBING LOCATION PLAN - PROPOSED

SCALE 1/4"

10' 20'1' 5'

PLUMBING NOTES

• PROVIDE AND INSTALL FIXTURES AS NOTED ON THE DRAWINGS.

• PROVIDE ALL ACCESSORIES, STRAPS, INSULATION AND OTHER MATERIALS REQUIRED FOR COMPLETE INSTALLATION.

• FURNISH AND INSTALL A COMPLETE SYSTEM OF SANITARY DRAINAGE, AND VENTING FOR THE PROJECT INCLUDING EXCAVATION, BACKFILL, DRAINAGE LINES, VENTS, VENT

STACKS, BOOTS, TRAPS, ALL NECESSARY CONNECTIONS TO A PUBLIC SEWER LINE.

• FURNISH AND INSTALL A COMPLETE WATER SUPPLY SYSTEM FOR THE PROJECT INCLUDING WATER SERVICE CONNECTION, PIPE LINES, DRAINS, FITTINGS, CONNECTIONS TO

PLUMBING FIXTURES, AND ALL NECESSARY ACCESSORIES TO PROVIDE A COMPLETE WORKABLE INSTALLATION.

• PROVIDE POWER FOR EXISTING IRRIGATION CONTROLLER. EXISTING IRRIGATION SYSTEM TO REMAIN, ANY MODIFICATIONS REQUIRED TO BE UNDER SEPARATE CONTRACT.

• THE GENERAL CONTRACTOR AND ALL SUB-CONTRACTORS SHALL BE RESPONSIBLE FOR THE ENFORCEMENT OF ALL REQUIREMENTS AND REGULATIONS AND SHALL PERFORM

ALL WORK ON THIS PROJECT IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT AND TEXAS ACCESSIBILITY STADARDS 2012

• ALL CONDITIONS SHOWN ON THIS SHEET MAY NOT BE REQUIRED BY THIS PROJECT. COMPARE THE REQUIREMENTS OF THE ARCHITECTURAL DRAWINGS WITH THIS SHEET FOR

RELEVANCE OF INFORMATION.

• NOTIFY THE ARCHITECT IMMEDIATELY OF ANY DISCREPANCY BETWEEN THE ARCHITECTURAL DRAWINGS AND INFORMATION GIVEN ON THIS SHEET FOR CLARIFICATION.

PROJECT CLOSEOUT

• THE CONTRACTOR SHALL PAY FOR AND OBTAIN FROM THE CITY, MUNICIPALITY, OR OTHER GOVERNING BODY, THE “CERTIFICATE OF OCCUPANCY” AND/OR OTHER NECESSARY

DOCUMENTS FOR THE OWNER TO FULLY OCCUPY AND OPERATE THE COMPLETED PROJECT IN ACCORDANCE WITH ALL APPLICABLE LAWS AND ORDINANCES.

• CLEAN-UP: THE CONTRACTOR AT ALL TIMES SHALL KEEP THE PROJECT SITE FREE FROM ACCUMULATION OF WASTE MATERIALS OR RUBBISH CAUSED BY HIS OPERATIONS. AT

THE COMPLETION OF EACH TRADE OF THE WORK, AND AT FINAL COMPLETION, AND NOT LATER THAN SEVEN DAYS BEFORE FINAL PAYMENT, HE SHALL REMOVE ALL HIS WASTE

MATERIALS AND RUBBISH FROM AND ABOUT THE PROJECT AS WELL AS ALL HIS TOOLS, CONSTRUCTION, EQUIPMENT, MACHINERY AND SURPLUS MATERIALS.

JUDSON NATURE TRAIL BUILDING

CITY OF ALAMO HEIGHTS

6116 BROADWAY

ALAMO HEIGHTS, TEXAS 78209

TTACHMENT A

SUBMITTAL COVER / SIGNATURE SHEET

ISSUE DATE:

September 12, 2018

Request For Proposal Title

RENOVATION OF JUDSON

NATURE TRAIL BUILDING

DATE OF CLOSING:

TIME OF CLOSING:

OCTOBER 12, 2018

(No later than)

2:00 p.m. CDT

DEPARTMENT:

ADMINISTRATION

DEPARTMENT

SUBMIT TO:

City of Alamo Heights

6116 Broadway

San Antonio, TX 78209

READ AND SIGN BELOW. UNSIGNED COVER SHEETS WILL NOT BE ACCEPTED.

Legal Name of Firm:

Address:

City:

State: Zip Code:

Contact Person:

Office Phone Number: Alternate Phone Number:

E-Mail Address: Fax Number:

gnature of Authorized Individual Typed Name of Authorized Individual

Date Typed Title of Authorized Individual

JUDSON NATURE TRAIL BUILDING

ATTACHMENT B

Regulatory Compliance and Criminal History Warranty; Acknowledgement

Fiduciary Duty Owed by Contractor to City

(a) Compliance. Histories, Warranty, Fiduciary Duty, Discretionary

Termination. The successful bidder [proponent] must demonstrate to the City’s

satisfaction that bidder [proponent] has clean environmental, criminal, and other

compliance histories with state, federal, and local agencies or authorities. By

submission of a bid or proposal in response to this solicitation, bidder [proponent]

Warrants to the City that he / she / it (in the case of a corporation or other legal entity)

including advisors, executive and supervisory employees, agents and

representatives, are in good stead with all regulatory authorities that may have

interests in or jurisdiction over the work activity or service bid [proposed] by the

Contractor. Regulatory interest or jurisdiction may go directly to the Contract activity in

question, to potential consequences of the activity, or indirectly to any regulated matter

that may reflect upon the Contractor’s competency and integrity. The City relies upon

Contractor’s Warranty and shall treat the Contractor as having a special fiduciary

duty to the City in this respect due to potential for environmental, third party

, and

other regulatory liabilities which may attend this Contract, including but not limited to

regulatory criminal responsibility. Contractor acknowledges such fiduciary duty to

the

City, promising a high standard of performance and best efforts to protect the public

interest against consequences of environmental mishap. Contractor warrants that no

matters pertaining to violations, notices of violation, or notices of regulatory concern

are now pending against Contractor or those persons (employees / affiliates) of concern

mentioned above; and that no civil or criminal litigation, and no man

ner of

enforcement activity, however preliminary, is

pending

against Contractor or those

persons, regardless of category or class of violation or potential violation.

If any such

matters are pending, Contractor must reveal and explain those matters in writing at

the time his / her / its bid [proposal] is tendered to the City.

If any such matters have

been resolved,

during the last five (5) years

, Contractor must similarly reveal and

explain same to the City with the bid [proposal] submission. The City retains the

right to determine, according to its discretion, whether or not a pending, unresolved,

or resolved enforcement issue or criminal matter concerning Contractor, its

operations, or employees / agents / representatives may impact the responsible

status of Contractor, i.e., render the Contractor unqualified, or detract from

Contractor’s competency standing. In reliance on Contractor’s Warranty, the City

reserves to itself the right to terminate the Contract, without further obligation upon

the City and without further recourse or remedy for the Contractor

except that the City

shall duly pay Contractor for work or services performed to date of termination,

should the City determine, following award of the Contract that Contractor failed to

reveal and explain to the City's satisfaction any such matters having regulatory or

criminal import or implications.

(b) Criminal Histories. Pending and

Resolved; Termination. Contractor must disclose and explain in writing any pending

criminal matters associated with his / her / its business operation. This disclosure

goes to Contractor’s person, and to all persons working for Contractor in a supervisory,

advisory, executive, agency, or in any representative capacity or manner

associated with Contractor’s business enterprise, which person(s) have any criminal

enforcement action pending against him or her, regardless of class or category of

alleged violation which may be pending, however preliminary, including

investigation. And concerning resolved criminal matters,

Contractor must make similar written disclosures and explanations for the same

category of persons, which disclosures and explanations concern any criminal

enforcement action that may have been resolved against such persons during the

JUDSON NATURE TRAIL BUILDING

last five (5) years. Failure to make such disclosures and explanations, with the

submission of the bidder’s [proponent’s] response to the City’s solicitation, shall be

grounds for the City’s termination of the Contract, should such information come to

the City’s attention after award of the contract; in which case, Contractor shall be

without recourse and remedy, except for the City’s payment to Contractor for services or

work performed up to date of termination.

(c)

Voidable Contract.

Contractor’s failure to abide by disclosure and

explanation requirements, in (a) and (b), above, shall render the Contract

voidable at the City’s discretion, with no compensation due Contractor, if

concealed or undisclosed violations, or undisclosed or concealed investigations

leading to formal criminal charges, are of such portent, in the City’s judgment, as to

place the

City in a position of regulatory or third party liability exposure, or

shall

pose or result in a threat to the public health, safety, or welfare. Any sums paid

Contractor, in the event of a voided contract, shall be recoverable by the City, in

addition to and cumulative of any other legal or equitable remedies the City may

have. Contractor understands the City shall enjoy the termination and void

able

contract remedies set forth in paragraph (b) and this paragraph (c) due to the

fiduciary duty owing from Contractor to City and due to the City’s reliance on the

Contractor’s Warranty of Regulatory Compliance and clean Criminal Hi

story.

JUDSON NATURE TRAIL BUILDING 1

ATTACHMENT C

RESPONDENT’S QUESTIONNAIRE

1. Respondent Information:

Provide the following information regarding the Respondent.

(NOTE: Co-Respondents are two or more entities proposing as a team or joint venture with each

signing the contract, if awarded. Sub-contractors are

not

Co-Respondents and should not be identified

here. If this proposal includes Co-Respondents, provide the required information in this Item #1 for each

Co-Respondent by copying and inserting an additional block(s) before Item #1.2. If Joint Venture or

Partnership, attach Joint Venture or Partnership Agreement.)

Respondent Name: ___________________________________________________________

(NOTE: Give exact legal name as it will appear on the contract, if awarded.)

Principal Address: __________________________________________________________________

City: ____________________________________ State: ________________Zip Code: ________________

Telephone No. : ______________________________ Fax No: _____________________________

Social Security Number or Federal Employer Identification Number: _________________________

Texas Comptroller’s Taxpayer Number, if applicable: _____________________________________

(NOTE: This 11-digit number is sometimes referred to as the Comptroller’s TIN or TID.)

Business Structure: Check the box that indicates the business structure of the

Respondent.



Individual or Sole Proprietorship

If checked, list Assumed Name, if any:



Partnership



Corporation If checked, check one:



For-Profit



Nonprofit

Also, check one:



Domestic



Foreign



Other: If checked, list business structure: ______________________________________

2. Contact Information:

List the one person who the City may contact concerning your bid or

setting dates for meetings.

Name: ______________________________________________________________________

Address:

City: ___________________________________ State: ________________Zip Code: __________

Telephone No. : _____________________________ Fax No: _______________________

Email:

Does Respondent anticipate any mergers, transfer of organization ownership,

reorganization, or departure of key personnel within the next twelve (12)

months?

JUDSON NATURE TRAIL BUILDING

4. Is Respondent authorized and/or licensed to do business

in Texas?

Yes



If “Yes”, list

authorizations/licenses.

Where is the Respondent’s corporate headquarters located? _____________________

Local Operation:

Does the Respondent have an office located in Bexar County, Texas?



If “Yes”, respond to a and b below:

a. How long has the Respondent conducted business from its

Bexar County office? Years Months

b. ____________________________________________________________________________ S

tate the number of full-time employees at the Bexar County office. ___________________

Debarment/Suspension Information:

Has the Respondent or any of its principals been

debarred or suspended from contracting with any public entity?

Yes



If “Yes”, identify the public entity and the name and current phone number of a

epresentative of the public entity familiar with the debarment or

suspension, and state the reason for or circumstances surrounding

the debarment or suspension, including but not limited to the

period of time for such debarment or suspension.

8. Bankruptcy Informa

tion:

Has the Respondent ever been declared bankrupt or filed

for protection from creditors under state or federal proceedings?

Yes



If “Yes”, state the date, court, jurisdiction, cause number, amount of liabilities

and amount of assets.

List here, any other names under which Respondent has operated within the last 10 years.

JUDSON NATURE TRAIL BUILDING

ATTACHMENT D

LITIGATION DISCLOSURE

Respond to each of the questions below by checking the appropriate box. Failure to fully and

truthfully disclose the information required by this Litigation Disclosure form may result in the

disqualification of your proposal from consideration or termination of the contract, once

awarded.

Have you or any member of your Firm or Team to be assigned to this engagement ever been

indicted or convicted of a felony or misdemeanor greater than a Class C in the last five (5)

years?

Yes



Have you or any me

mber of your Firm or Team to be assigned to this engagement been

terminated (for cause or otherwise) from any work being performed for the City of Alamo

Heights or any other Federal, State or Local Government, or Private Entity?

Yes



Have you or any member of your Firm or Team to be assigned to this engagement been involved in

any claim or litigation with the City of Alamo Heights or any other Federal, State or Local

Government, or Private Entity during the last ten (10) years?

Yes



If you have answered “Yes” to any of the above questions, please indicate the name(s)

of the person(s), the nature, and the status and/or outcome of the information, indictment,

conviction, termination, claim or litigation, as applicable. Any such information should

be provided on a separate page, attached to this form and submitted with your

proposal.

JUDSON NATURE TRAIL BUILDING

ATTACHMENT E

INSURANCE REQUIREMENTS

Contractors performing work or services on City property or public right-of-way for the City

of Alamo Heights shall provide the City a certificate of insurance evidencing the

coverages and coverage provisions identified herein. Contractors shall provide the City

evidence that all subcontractors performing work or services have the same types and

amounts of coverages as required herein or that the subcontractors are included under the

contractor’s policy. The City, at its own discretion, may require a certified copy of the policy.

All insurance companies and coverages must be authorized by the Texas

Department of Insurance to transact business in the State of Texas and must be

acceptable to the City of Alamo Heights.

Listed below are the types and amounts of insurance required. The City reserves the right to

amend or require additional types and amounts of coverages or provisions depending on the

nature of the work.

Type of Insurance Amount of Insurance Provisions

1. Workers’ Compensation

2. Employer’s Liability

Statutory

$100,000 each accident

City to be provided a waiver

of subrogation.

3. Commercial General Liability to

include coverage for the following:

a. Premises/O

perations

b. Products/C

ompleted

Operations

Independent Contractors

d. Personal Injury

e. Contractual

Liability

f. Personal/Advertising Injury

. Medical Expenses

$1,000,000 each occurrence,

$1,000,000 general aggregate;

$1,000,000 combined single limits

City to be listed as additional

insured and provided 30-day

notice of cancellation or

material change in coverage.

City prefers that insurer be

rated B+VI or higher by A.M.

Best or A or higher by

Standard & Poors.

4. Business Automobile Liability

a.Owned/leased vehicles

b.Non-owned vehicles

c.Hired vehicles

Combined Single Limit for Bodily

Injury and Property Damage of

$1,000,000 per occurrence.

5. Crime/Employee Dishonesty*

(including monies and securities)

$250,000

6. Indemnification Bond* $250,000

If applicable.

JUDSON NATURE TRAIL BUILDING

ATTACHMENT F

INDEMNIFICATION REQUIREMENTS

If selected to provide the services described in this RFP, Respondent shall be required

to comply with the indemnification requirements set forth below:

RESPONDENT covenants and agrees to FULLY INDEMNIFY and HOLD

HARMLESS, the CITY and the elected officials, employees, officers, directors, volunteers

and representatives of the CITY, individually or collectively, from and against any and all

costs, claims, liens, damages, losses, expenses, fees, fines, penalties, proceedings, actions,

demands, causes of action, liability and suits of any kind and nature, including but not limited

to, personal or bodily injury, death and property damage, made upon the CITY directly or

indirectly arising out of, resulting from or related to RESPONDENT’s activities under this

CONTRACT, including any acts or omissions of RESPONDENT, any agent, officer,

director, representative, employee, consultant or subcontractor of RESPONDENT, and

their respective officers, agents, employees, directors and representatives while in the

exercise of performance of the rights or duties under this CONTRACT, all without however,

waiving any governmental immunity available to the CITY under Texas Law and without

waiving any defenses of the parties under Texas Law. IT IS FURTHER COVENANTED

AND AGREED THAT SUCH INDEMNITY SHALL APPLY EVEN WHERE SUCH COSTS,

CLAIMS, LIENS, DAMAGES, LOSSES, EXPENSES, FEES, FINES, PENALTIES,

ACTIONS, DEMANDS, CAUSES OF ACTION, LIABILITY AND/OR SUITS ARISE IN ANY

PART FROM THE NEGLIGENCE OF CITY, THE ELECTED OFFICIALS, EMPLOYEES,

OFFICERS, DIRECTORS, VOLUNTEERS AND REPRESENTATIVES OF CITY, UNDER

THIS CONTRACT. HOWEVER THE SCOPE OF INDEMNITY IMPOSED ON RESPONDENT

BY THIS AGREEMENT DOES NOT EXTEND TO ACTIONS TAKEN BY RESPONDENT OR

ITS AGENTS IN DIRECT RESPONSE AND IN COMPLIANCE WITH ORDERS AND

DIRECTIONS GIVEN TO RESPONDENT AND IT AGENTS BY THE CHIEF OF POLICE OR

HIS REPRESENTATIVE OR SENIOR FIREFIGHTERS IN CONTROL OF AN ACCIDENT

SCENE.

It is the EXPRESS INTENT of the parties to this CONTRACT, that the INDEMNITY

provided for in this section, is an INDEMNITY extended by RESPONDENT to INDEMNIFY,

PROTECT and HOLD HARMLESS, the CITY from the consequences of the CITY'S OWN

NEGLIGENCE, provided however, that the INDEMNITY provided for in this section SHALL

APPLY only when the NEGLIGENT ACT of the City is a CONTRIBUTORY CAUSE of the

resultant injury, death, or damage, and shall have no application when the negligent act of

the City is the sole cause of the resultant injury, death, or damage. RESPONDENT further

AGREES TO DEFEND, AT ITS OWN EXPENSE and ON BEHALF OF THE CITY AND IN

THE NAME OF THE CITY, any claim or litigation brought against the CITY and its elected

officials, employees, officers, directors, volunteers and representatives, in connection with

any such injury, death, or damage for which this INDEMNITY shall apply, as set forth above.

However, given the industrial character, history, and intended use of the site, subject

of this RFP, the foregoing contributory cause provision shall not relieve the RESPONDENT

of the obligation to fully indemnify, defend, and hold harmless the CITY and all those persons

recited above, according to the foregoing paragraphs, when the claim, demand, criminal or

civil action, regulatory enforcement action, demand or direction for remediation is brought by

an environmental regulatory agency or division, local, state, or federal, in which case THE

SELECTED RESPONDENT SHALL INDEMNIFY, DEFEND, AND HOLD HARMLESS THE

CITY, ITS ELECTED OFFICIALS, EMPLOYEES, OFFICERS, DIRECTORS AND

REPRESENTATIVES, FOR THE CITY’S ALLEGED OR PROVEN NEGLIGENCE EVEN

WHEN THE CITY’S SOLE NEGLIGENCE MAY BE ALLEGED OR PROVEN.

JUDSON NATURE TRAIL BUILDING

The provisions of this INDEMNIFICATION are solely for the benefit of the parties

hereto and not intended to create or grant any rights, contractual or otherwise, to any other

person or entity.

RESPONDENT shall advise the CITY in writing within 24 hours of any claim or

demand against the CITY or RESPONDENT known to RESPONDENT related to or arising

out of RESPONDENT’s activities under this contract, and shall see to the investigation and

defense of such claim or demand at RESPONDENT’s cost. The CITY shall have the right, at

its option and at its own expense, to participate in such defense without relieving

RESPONDENT of any of its obligations under this paragraph.

JUDSON NATURE TRAIL BUILDING

ATTACHMENT G

CONFLICT OF INTEREST QUESTIONNAIRE

FORM

CIQ

For vendor or other person doing business with local governmental entity

This questionnaire is being filed in accordance with chapter 176 of the Local

Government Code by a person doing business with the governmental entity.

By law this questionnaire must be filed with the records administrator of the local

government not later than the 7th business day after the date the person becomes

aware of facts that require the statement to be filed. See Section176.006, Local

Government Code.

A person commits an offense if the person violates Section 176.006, Local

Government Code. An offense under this section is a Class C misdemeanor.

OFFICE USE ONLY

Date Received

1) Name of person doing business with local governmental entity.



Check this box if you are filing an update to a previously filed

questionnaire.

(The law requires that you file an updated completed questionnaire with the appropriate filing authority not later

than September 1 of the year for which an activity described in Section 176.006(a), Local Government Code, is

pending and not later than the 7th business day after the date the originally filed questionnaire becomes

ilti t)

3) Describe each affiliation or business relationship with an employee or contractor of the

local governmental entity who makes recommendations to a local government officer of the

local governmental entity with respect to expenditure of money.

4) Describe each affiliation or business relationship with a person who is a local government

officer and who appoints or employs a local government officer of the local governmental entity that is

the subject of this questionnaire.

JUDSON NATURE TRAIL BUILDING

CONFLICT OF INTEREST QUESTIONNAIRE

FORM

CIQ

For vendor or other person doing business with local governmental entity Page 2

5) Name of local government officer with whom filer has affiliation or business relationship.

(Complete this section only if the answer to A, B, or C is YES.)

This section, item 5 including subparts A, B, C & D, must be completed for each officer with

om the filer has affiliation or business relationship. Attach additional pages to this Form

CIQ as necessary.

A. Is the local government officer name in this section receiving or likely to receive taxable income

from the filer of the questionnaire?

 Yes  No

B. Is the filer of the questionnaire receiving or likely to receive taxable income from or at the

direction of the local government officer named in this section AND the taxable income is not from

the local governmental

entity?

 Yes  No

C. Is the filer of this questionnaire affiliated with a corporation or other business entity that the

local government officer serves as an officer or director, or holds an ownership of 10 percent

or more?

 Yes  No

D. Describe each affiliation or business relationship.

6) Describe any other affiliation or business relationship that might cause a conflict of interest.

Signature of p

erson doing business with the governmental entity Date

JUDSON NATURE TRAIL BUILDING

ATTACHMENT H

VENDOR ACKNOWLEDGEMENT FORM

THIS FORM MUST BE THE LAST PAGE OF YOUR ORIGINAL PROPOSALS AND COPIES!

The undersigned hereby certifies that he/she understands the specifications, has read the

document in its entirety and that the prices contained in this proposal have been carefully

reviewed and are submitted as correct and final. Vendor further certifies and agrees to

furnish any or all products/services upon which prices are extended at the price offered,

and upon conditions contained in the specifications of the proposal.

The following information must be filled out in its entirety for your proposal to be considered.

Company Name:

Address of Principal Place of Business:

Phone/Fax of Principal Place of Business:

Address, Phone and

Fax of Majority Owner

Principal Place of

Business:

E-mail Address of Representative: _______________________________________________

Authorized Representative:

Signature Date

Printed Name

Download
Save PDF to desktop

Email
Email completed PDF

Send for Signing
Email for others to sign

Print
Print document

NAME

Judson Nature Trail Building Bid Set 09.12.2018 (City of Alamo Heights)

View Audit Log
Print With Audit Log
Duplicate Document

Fill Online, Printable, Fillable, Blank Judson Nature Trail Building Bid Set 09.12.2018 (City of Alamo Heights) Form

Related forms

Fillable Judson Nature Trail Building Bid Set 09.12.2018 (City of Alamo Heights)

Fill Online, Printable, Fillable, Blank Judson Nature Trail Building Bid Set 09.12.2018 (City of Alamo Heights) Form

Related forms

First 20 documents completely FREE!