George Latimer
County Executive
Department of Consumer Protection
James Maisano
Director
John P. Gaccione
Deputy Director
and County Sealer
148 Martine Avenue, Room 407
White Plains, New York 10601 Telephone: (914) 995-2155 Fax: (914) 995-5259 Website: www.westchestergov.com/consumer
Attention Home Improvement Contractor:
Enclosed and/or attached, please find the application packet for the Westchester County Home
Improvement License for a company OWNER seeking licensure. This packet includes:
The Application Form - If obtained online: You may fill in the fields using the keyboard and print.
You must sign the form before a notary and the notary must stamp and sign as well.
The Instruction Sheet (see reverse side of this letter).
A copy of the Laws Governing Westchester County Home Improvement Contractors.
A Child Support Certification Form - If obtained online: You may fill in the fields using the keyboard
and print. You must sign the form before a notary and the notary must stamp and sign as well.
A Notice to Business Summary for Licensees.
A Credit Card Authorization Form - To be utilized only for expedited applications.
Until further notice, applications are to be submitted via mail or other delivery service.
Visitors are not permitted into the department. Emailed or faxed applications are not acceptable.
Please note that incomplete applications will NOT be accepted and will be returned in their
entirety, so you must ensure all forms are complete and all requested documents have current/valid
dates where applicable and meet the provisions indicated on the reverse side.
Please carefully review these instructions and documents. Should you have any questions about the
application or licensing process, feel free to call the Department of Consumer Protection between
9:00 a.m. and 3:00 p.m. at 914-995-2155 or 914-995-2211.
The licensing process, including document verification and background investigation, takes approximately
sixty (60) business days to complete. Should you choose, you may elect to have your application
expedited for an additional non-refundable fee of seventy-five dollars ($75.00). An expedited application
will be processed within seven (7) business days once your credit card has been charged and your
license certificate and decal(s) will be mailed to you after the application has been approved. Please be
advised that any application found deficient or questionable in any way will cause a delay in the expedited
process and you will forfeit this fee. All fees must be paid by credit card should you choose this option.
PLEASE NOTE: The CITY OF YONKERS has additional licensing requirements.
You may call (914) 377- 6807 for complete information.
Please Note:
Upon renewal, all Home Improvement License
RENEWAL Forms will be sent to each applicant
electronically. You must ensure that this office has your
current and accurate email address on file. Should your
email address change at any time, you must notify
this office in writing immediately.
Please Also Note:
The department is operating to assist with any questions or
concerns. You may reach us via the following methods:
Phone: (914) 995-2155 or (914) 995-2211
Email: conpro@westchestergov.com
Fax: (914) 995-3115
To be considered for LICENSING, you must submit the following to the Westchester County Department of
Consumer Protection, Licensing Division, 148 Martine Avenue, Room 407, White Plains, NY 10601.
1) COMPLETED ORIGINAL APPLICATION form with NOTARIZED SIGNATURE OF THE APPLICANT (Owner).
Please PRINT in blue or black ink only. If a question does not pertain to you, enter "N.A." on that line.
2) Two year non-refundable application fee of Five Hundred Dollars ($500.00), payable to "WESTCHESTER
COUNTY GENERAL FUND". Checks or Money Orders are the accepted forms of payment.
3) PROOF OF BUSINESS NAME: Copy of your Business Certificate, Partnership Certificate, Articles of
Organization (LLC, LLP, etc.) Filing Receipt, Certificate of Incorporation Filing Receipt and/or Certificate
of Assumed Name Filing Receipt where applicable. Must be from the state/municipality you operate from.
4) If your business is a SOLE PROPRIETORSHIP, the proprietor must submit a NOTARIZED CHILD SUPPORT
CERTIFICATION FORM. If your business is a PARTNERSHIP, each partner must submit a NOTARIZED CHILD
SUPPORT CERTIFICATION FORM.
5) LIABILITY INSURANCE CERTIFICATE, naming the Westchester County Department of Consumer Protection,
148 Martine Avenue, Room 407, White Plains, NY 10601 as CERTIFICATE HOLDER. In addition, the Certificate
should indicate the operations performed by the insured that are covered under the policy. You may list any
EXCLUSION(S) under the policy. Examples of Exclusions: Roofing, Siding, Paving, Excavation, Tree
Cutting/Removal, etc. (as appropriate to your business). Policy dates must be current.
6) WORKERS’ COMPENSATION AND DISABILITY [show proof of either (A) and (B) or (C), as applicable]:
(A) NYS WORKERS COMPENSATION INSURANCE CERTIFICATE, (Form U-26.3 OR C-105.2) naming the
Westchester County Department of Consumer Protection, 148 Martine Avenue, Room 407, White Plains, NY
10601 as CERTIFICATE HOLDER. Policy dates must be current.
(B) NYS DISABILITY INSURANCE CERTIFICATE (Form DB-120.1 OR DB-155) naming the Westchester
County Department of Consumer Protection, 148 Martine Avenue, Room 407, White Plains, NY 10601 as
CERTIFICATE HOLDER. Policy dates must be current.
~ OR IF ELIGIBLE ~
(C) WORKERS’ COMPENSATION/DISABILITY EXEMPTION AFFIDAVIT (Form CE-200). To obtain Form
CE-200, please contact the NYS Workers’ Compensation Board online at www.wcb.ny.gov . Must indicate
“Business Applying For:Home Improvement License From:” Westchester County Department of
Consumer Protection as Licensing Agency. You must also indicate your EXACT business name and status.
NOTE: Affidavit must be completed and SIGNED prior to submitting the License Application.
**ALL INSURANCE DOCUMENTS MUST BE IN THE EXACT/CORRECT COMPANY NAME AND NOT EXPIRED**
7) Clear copy of a VALID PHOTO DRIVER’S LICENSE and Proof of Current Home Street Address, if different
from the Driver’s License, for all individuals named in question numbers 5 and 6. Proof of address accepted:
Lease, Mortgage Statement, Homeowners Insurance Bill, Utility Bill or Vehicle Registration. Proof MUST be
current. Cell phone bills & credit card/bank statements are not acceptable. If you do not have driving privileges,
you may submit a VALID non-driver photo identification document issued from a government agency, along
with proof of home address.
8) Copies of current Vehicle Registrations for each decal requested. Minimum of one required. Must be in the
name of the company, applicant, owner(s)/officer(s). Decals are NOT required for trailers and will not be issued
for them. In addition, copies of vehicle registration window stickers, temporary certificates of registration and
vehicle titles are not acceptable.
9) Copies of BOTH: NEW YORK STATE DEPT. OF ENVIRONMENTAL CONSERVATION Pesticide Business
Registration Certificate AND Pesticide Applicator/Technician Photo Identification Card, where applicable.
6/2021
George Latimer, Westchester County Executive
DEPARTMENT OF CONSUMER PROTECTION
148 Martine Avenue - Room 407
White Plains, New York 10601
Telephone #: (914) 995-2211
www.westchestergov.com/consumer
HOME IMPROVEMENT LICENSE APPLICATION
All information must be accurate and complete. Please type or CLEARLY and NEATLY print all requested information using blue or black ink.
Until further notice, applications are to be submitted via mail or other delivery service.
Visitors are not permitted into the department. Emailed or faxed applications are not acceptable.
Please read the enclosed instruction sheet before completing this application.
(1) Type of Ownership: ( ) Individual ( ) Partnership ( ) LLC ( ) Corporation
(2) Name of Company: ___________________________________________________________________________________
(3) D/B/A, Trade, or Assumed Name: (If same as #2, enter N/A) - __________________________________________________
(4) Business Address: _______________________________________ Apt/Suite # _______ Phone #: ( ) ______________
City: _______________________________ State: ________ Zip Code: ____________ Fax #: ( ) __________________
(5) Name of Applicant: (Owner) - _____________________________________________ Company Title: _________________
Date of Birth: ______________ Driver License Number: ____________________ Home Phone #: ( ) _______________
Home Street Address: _____________________________________________________ Apt/Suite # __________________
City: ___________________________ State: ________ Zip Code: ___________ Cell Phone #: ( ) _________________
Email Address: ______________________________________________________________________________________
(6) List EACH ADDITIONAL responsible individual involved with the company. Include Co-owners, Officers, Members,
Partners, Managers, and Salespersons: (Any individual authorized to estimate, negotiate, and/or finalize contracts)
OWNER(S) MUST NOTIFY THIS OFFICE UPON ANY CHANGES IN COMPANY RESPONSIBLE INDIVIDUALS.
NAME TITLE FULL HOME ADDRESS HOME TELEPHONE # DATE OF BIRTH
(7) This company engages in the following work: (Check ALL that apply)
Carpentry ( ) Chimney Work ( ) Kitchen/Bath ( ) HVAC ( ) Landscaping ( ) Masonry ( ) Painting ( )
Tree Removal ( ) Paving ( ) Pools ( ) Roofing ( ) Siding ( ) Tile ( ) Windows ( ) General Contractor ( )
Alternative Energy ( ) Other ( ) Please Specify: _________________________________________________________
_____________________________________________________________________________________
FOR OFFICE USE ONLY
Date Received: ____________ Amount Paid: $ __________ Check #: ________________ License Number: ____________
(8) Is this company licensed in any other jurisdiction? …………………………………………………………..…. ( ) Yes ( ) No
If Yes, list jurisdiction(s) AND license number(s): __________________________________________
(9) Does the company or any affiliate arrange or facilitate the financing of home improvement contracts? . ( ) Yes ( ) No
(10) Has the applicant or any principal in the company ever been convicted of a crime? ……………………. ( ) Yes ( ) No
If Yes, list the individual(s), crime(s) and nature of, jurisdiction(s), year(s) and disposition(s) and provide related documents.
_____________________________________________________________________________________________________
(11) Has this company, any other current or previously owned company or any principals had ANY
Trade Application(s) or License(s) Denied, Revoked or Suspended? ……………………………………….. ( ) Yes ( ) No
If Yes, list the company name(s), individual(s), type of license(s), jurisdiction(s), and reason(s): LIST ALL INSTANCES
_____________________________________________________________________________________________________
(12) Is/Are there any outstanding unsatisfied business related Judgment(s) against the business
listed on this application or its principals? ………………………………………………………………………. ( ) Yes ( ) No
If Yes, list the business name, individual(s) and date and location of the filing(s) and provide related documents.
_____________________________________________________________________________________________________
(13) Is/Are there any outstanding unsatisfied business related Judgment(s) against any other
current or previously owned business(es) or corporation(s)? …………………………………………….... ( ) Yes ( ) No
If Yes, list the business/corporation name(s) and date and location of the filing(s) and provide related documents.
_____________________________________________________________________________________________________
(14) Is/Are there any outstanding unsatisfied administrative decisions, determinations of liability and/or judgments related to
the underpayment or non-payment of wages, against this business or a previously owned business and/or its principals?
………………………………………………………………………......................................................................( ) Yes ( ) No
If Yes, list the business name(s), all individuals involved and provide ALL related documentation.
_____________________________________________________________________________________________________
(15) Has there ever been a bankruptcy filing by this company, any other current or previously
owned company or its principals? ……………………………………………………………………………….. ( ) Yes ( ) No
If Yes, list the company name(s), individual(s), dates, index numbers and location(s) of the filing(s) and provide documents.
_____________________________________________________________________________________________________
(16) Please supply copies of the Vehicle Registration(s). Must indicate the number of decals needed…. # (______________)
(17) Does your business involve the utilization of Leaf Blower Equipment? ………………………………….... ( ) Yes ( ) No
If Yes: I hereby affirm that I am aware of the requirements of §863.327 (1) of the Westchester County
Consumer Protection Code (Leaf Blower Law) and I am in compliance with its provisions.
(18) Does this company engage in the application of pesticides? ………………………………………………. ( ) Yes ( ) No
If Yes, list the N.Y.S. - D.E.C. Business Registration Certificate Number _______________________,
Applicator/Technician Identification Card Number(s) _________________________________ AND provide copies of ALL.
______________________________________________________________________________________________________
Affidavit/Verification by the APPLICANT for the company. This application must be signed in the presence of a
Notary Public.
I hereby acknowledge that false statements made in this document are punishable as a Class A Misdemeanor
pursuant to §210.45 of the New York State Penal Law.
Under the penalty of perjury, I hereby swear that all of the information on this form and any attachments are
true and accurate and I shall notify the department of any changes in company responsible individuals. I also
understand that I waive any claim(s) to fees paid in relation to the application and licensing process.
(19) _____________________________________ ___________________________________ _______________________
Authorized Signature Print Name Print Applicant’s Company Title
(20) Subscribed and Sworn to before me, this _____________ Day of _____________________________, 20________ in the
County of _____________________________________, State of __________________________________________
______________________________________________
Signature of Notary Public 10/2020
LAWS GOVERNING THE LICENSING OF
HOME IMPROVEMENT CONTRACTORS
IN WESTCHESTER COUNTY
WESTCHESTER COUNTY CONSUMER PROTECTION CODE
ARTICLE IV
ARTICLE XVI
ARTICLE XIX
ARTICLE XXVI
ADMINISTRATIVE CODE
ARTICLE VIII
NEW YORK STATE GENERAL BUSINESS LAW
ARTICLE 36-A
NEW YORK STATE LIEN LAW
SECTION 71-a
Westchester County Department of Consumer Protection
Home Improvement Licensing Division
148 Martine Avenue, Room 407
White Plains, New York 10601
www.westchestergov.com
ARTICLE IV. RETAIL SALE, RENTAL AND REPAIR OF GOODS
Section 863.111. Sale of consumer services.
1. It shall be violation of this code for any merchant or other person engaged in the sale of consumer services
to be performed in the future to fail to:
a. conspicuously set forth in any contract, order form, receipt or other written memorandum a date to
commence and a date to complete the performance of the service; or
b. commence and complete the performance of the service on the date or dates agreed upon with the
consumer, unless:
(1). the consumer is notified in writing, or by oral communication confirmed in writing within one (1) day
of the delay and the revised date of commencement and/or completion; and
(2). the consumer agrees to the revised dates,
2. If the merchant or other person providing the service shall fail to comply with the requirement to disclose a
commencement and/or completion date as provided in Subdivision 1 of this section, or if the service has not
been performed within the period of time disclosed, the consumer, at his option may:
a. cancel the contract with full refund for uncompleted portions of the work providing the consumer has
paid in advance thereof; or
b. negotiate a new commencement and/or completion date with the merchant.
ARTICLE XVI. LICENSING OF PERSONS ENGAGED IN THE HOME IMPROVEMENT BUSINESS
Section 863.311. Legislative Findings.
It is hereby declared and found that because of the increase in complaints by residential dwellers in the County
of Westchester about abuses on the part of home improvement contractors, it has become desirable to
safeguard and protect such residents by regulating the home improvement, remodeling and repair business and
by licensing persons engaged in such business. Such licensing will protect and promote the health, safety and
welfare of the residents of the County of Westchester.
Section 863.312. Definitions.
Unless the context otherwise specifically requires, the following terms, when used in this Article, shall have the
following meanings:
1. "Contractor" means any person who owns, operates, maintains, controls, transacts or conducts a home
improvement business or who undertakes, facilitates or advertises a home improvement service or offers to
undertake, facilitate or agrees to perform any home improvement. A person shall be deemed to facilitate a
home improvement service when, for a fee, they organize, oversee, or arrange for other Contractors to perform
home improvement services.
2. "Home improvement" means a repair, replacement, remodeling, installation, construction, alteration,
conversion, modernization made to, in or upon a private residence, apartment or dwelling place of not more than
three units, including, but not limited to the following:
a. waterproofing;
b. exterior siding, awnings, leaders and gutters;
c. decks, patios, garages, carports and additional rooms;
d. storm and/or replacement windows and doors;
e. roofs;
f. driveways and walkways;
g. kitchens and bathrooms;
h. masonry;
i. fence installations;
j. chimney maintenance;
k. exterior and interior painting;
l. landscaping and gardening;
m. arboriculture;
n. tile setters;
o. swimming pools;
p. underground sprinkler systems;
q. excavation; and
r. other similar improvements.
3. "Home improvement business" means the business of providing for a profit, a home improvement to an
owner, provided, however, the term shall not include labor or services performed by an employee for a
contractor.
4. "Home improvement contract" means an agreement between a contractor and an owner for the
performance of a home improvement, and includes all labor, services and materials to be furnished and
performed there under, either directly by the contractor or by another person under separate agreement with
the contractor.
5. “Leaf blower” means any portable device powered by a self contained internal combustion engine, which is
commonly used in landscaping and property maintenance to blow, disperse or redistribute dust, dirt, leaves,
grass clippings, cuttings, trimmings from trees or shrubs, or other debris on sidewalks, driveways, lawns, or
other surfaces.
6. "Licensee" means a person licensed to engage in the home improvement business under the provisions of
this Article.
7. "Owner" means a homeowner, tenant, or any other residential dweller who orders, contracts for, or
purchases a home improvement.
8. "Person" means an individual, firm, company, partnership, association, corporation or other business entity.
9. “Affiliate” shall mean any person controlling, controlled by, or under common control with a licensee or
contractor. The terms “control”, “controlled” or “controlling shall mean the possession, direct or indirect, of the
power to cause the direction of management and policies of such controlled person. The ownership, directly or
indirectly, of at least fifty-one percent (51%) of the voting securities of, or the possession of the right to vote, in
the ordinary direction of its affairs, of fifty-one percent (51%) of the voting interest in, any person shall be
presumed to constitute such control.
Section 863.313. License Required; Home Improvement Business.
1. No person shall maintain, conduct, advertise, operate, or engage in the home improvement business within
the county of Westchester, or hold himself or herself out as being able to do so, unless such person is licensed
pursuant to this Article.
2. Upon issuance of a home improvement license under the provisions of this chapter, the Director or Sealer
shall issue a vehicle decal for each vehicle identified by the licensee as a vehicle which will be used in
connection with the licensed activities. Such vehicle decals shall be conspicuously displayed in or on the
vehicle(s) used in connection with the licensed activities during the term of the license.
Section 863.314. Application for License or Renewal; affirmation regarding leaf blowers.
1. An application for a license under this Article, or a renewal thereof, shall be made in writing to the Director or
Sealer in accordance with such procedures, providing such information and on such forms as the Director or
Sealer may from time to time require. An application shall require any information the Director or Sealer deems
necessary to render a determination in accordance with this Chapter and shall, at a minimum, require the
disclosure of any final and non-appealable civil, criminal, or administrative business related judgments or
determinations of liability incurred by the applicant, or by any business for which applicant was an owner,
director, officer, member, or otherwise exercised control over the business, including but not limited to
judgments or determinations of liability related to the nonpayment or underpayment of wages. The application
shall be signed by the applicant and shall be accompanied by a check, cash or money order in the amount of
the fee required under Section 863.315 of this Article.
2. A contractor, engaged in the business of landscaping, gardening, arboriculture, or any similar outdoor
vocation, seeking to obtain or renew a license under this section, shall verify in writing that such contractor, its
agent or affiliate or employee is in compliance with Subsection 1 of Section 863.327 of this Chapter.
Section 863.315. Fees.
The non-refundable biannual fee for a license to conduct a home improvement business shall be five hundred
dollars ($500.00) and for each renewal thereof the fee shall be five hundred dollars ($500.00). The license to
conduct a home improvement business shall be for a period of two (2) years and each renewal thereof shall be
for two (2) years. The Director or Sealer may impose a penalty of twenty-five ($25.00) dollars upon a renewal
application received by the Director or Sealer later than fifteen (15) days prior to the expiration date of the
license sought to be renewed. The fee for issuing a duplicate license for one lost, destroyed or mutilated shall
be twenty-five dollars ($25.00).
Section 863.316. Grant or Denial of License or Renewal.
1. Within ninety (90) days after receipt of a complete application in proper form, the Director or Sealer shall
grant or deny a license, or renewal thereof, under this Article. The Director or Sealer shall grant the license or
renewal unless the Director or Sealer determines that the applicant:
a. Is not financially responsible. In making such a determination, the Director or Sealer shall take into
consideration all final non-appealable determinations of liability in any civil, criminal or administrative
actions including, but not limited to, those involving nonpayment or underpayment of wages rendered by
any local, state, or federal government court, agency, or division, including any such determinations
rendered against any business for which the applicant was an owner, director, officer, member, or
otherwise exercised control over the business.
b. Is unqualified to engage in the home improvement business;
c. Has made a false statement of a material fact in the application for a license under this Article;
d. Has outstanding against it, unsatisfied home improvement business-related judgments. In making such
a determination, the Director or Sealer shall take into consideration all final non-appealable
determinations of liability in any civil, criminal or administrative actions including, but not limited to, those
involving nonpayment or underpayment of wages rendered by any local, state, or federal government
court, agency, or division, including any such determinations rendered against any business for which the
applicant was an owner, director, officer, member, or otherwise exercised control over the business.
e. Has against it an unacceptable amount of home improvement complaints as determined by the Director
or Sealer.
A denial of a license or renewal shall be made by the Director or Sealer in writing and shall set forth a statement
of the reason or reasons therefor and shall be subject to administrative and judicial review in accordance with
Subdivision two of this Section.
2. Within thirty (30) days after a denial of an application for a license or a renewal thereof, the applicant shall
be entitled to demand a hearing before the Director or Sealer by making a written demand therefor. Following
receipt of such written demand, a hearing shall be held by the Director or Sealer, or by a deputy designated by
the Director or Sealer, or by such other person or persons designated by the Director or Sealer. A record of
such hearing shall be made. At such hearing the applicant may be represented by counsel and may offer
evidence in his or her behalf to demonstrate that a license or renewal should be granted. Compliance with
technical rules of evidence shall not be required. If a deputy or other person or persons is designated to hold
the hearing, such deputy or other designated person or persons shall refer the record and recommendations to
the Director or Sealer for determination. The determination made by the Director or Sealer shall be subject to
judicial review in accordance with Article 78 of the Civil Practice Law and Rules in a proceeding brought within
four (4) months after the determination is rendered.
Section 863.317. Revocation or Suspension of License.
1. In accordance with the procedure set forth in Subdivision two of this Section, the Director or Sealer may
revoke, or upon such conditions as the Director or Sealer deems appropriate, suspend for a period of time, a
license issued under this Article, provided, however, that no revocation or suspension imposed hereunder shall
be construed to impair or preclude a licensee's obligation to complete home improvement contracts in existence
on the date such revocation or suspension otherwise becomes effective. On the effective date of such
revocation or suspension the licensee shall furnish the Director or Sealer with a written list of such home
improvement contracts with respect to which licensee is under a legal obligation to perform, in accordance with
procedures authorized by Section 863.324 (5) of this Article.
2. Grounds for suspension or revocation shall include:
a. Grounds to deny a license or renewal under Section 863.316;
b. Failure by the licensee to fully and satisfactorily perform or furnish any labor, services or materials
included under a home improvement contract.
c. The commission by a licensee of an act or acts in violation of Section 863.319 of this Article.
3. The licensee shall be given written notice by the Director or Sealer of the commencement of the revocation
or suspension proceeding and a copy of the charges upon which the proceeding is brought. Service may be
made by ordinary mail to the address given in the application made by the licensee for a license under this
Article. The licensee shall answer the charges in writing within ten (10) days. A hearing on such charges shall
be held by the Director or Sealer or a deputy designated by the Director or Sealer, or by such other person or
persons designated by the Director or Sealer. A record of such hearing shall be made. At such hearing the
licensee may be represented by counsel and may offer evidence in his or her behalf. Compliance with technical
rules of evidence shall not be required. The burden of proving the charges by substantial evidence shall be
upon the Director or Sealer. If a deputy or other person or persons is designated to hold the hearing, such
deputy or other designated person or persons shall refer the record and recommendations to the Director or
Sealer for determination. The determination made by the Director or Sealer shall be subject to judicial review in
accordance with Article 78 of the Civil Practice Law and Rules in a proceeding brought within four (4) months
after the determination is rendered.
Section 863.318. License, Assignment.
Any license issued by the Director or Sealer under this Article shall not be assigned or transferred by the
licensee.
Section 863.319. Violations.
1. It shall be a violation to:
a. Abandon or fail to perform, or furnish, without justification, any labor, services or materials included under
a home improvement contract, or willfully deviate from the plans or specifications of a home improvement
contract in any material respect without the consent of the owner;
b. Conduct a home improvement business in any name other than the one in which the person is licensed;
c. Fail to agree in writing that the owner may cancel by written notice the home improvement contract
without penalty at any time prior to midnight on the third business day after the date such contract is made;
d. Make a false statement or provide false information in making application for a license, including a
renewal or duplicate license;
e. Fail to notify the Director or Sealer, in writing, of any change of control in the ownership, management or
business name or location of a home improvement business within ten (10) days thereof;
f. Fail to disclose on all advertising, stationery, proposals, change orders, and invoices for a home
improvement business, and in all contracts with an owner for a home improvement the number of the license
issued under this Article;
g. Fail to comply with the provisions of Section 863.325 of this Article;
h. Fail to comply with the provisions of Sections 863.326, 863.327, and 863.329 of this Article;
i. Operate a home improvement business without a license as required by this Article; or
j. Fail to provide direct supervision over subcontractors or employees hired by licensee at job site.
2. The foregoing acts are unlawful when committed by a person engaged in the home improvement business
within the County of Westchester and violations of the provisions of this Section proscribing certain acts shall be
enforced in accordance with and shall be subject to the penalties provided in the Laws of Westchester County,
including but not limited to Chapter 182, Article VIII of Chapter 277 and Article I of Chapter 863 thereof.
Section 863.320. Criminal Penalties.
Any person who shall maintain, conduct, operate or engage in a home improvement business within the County
of Westchester without a license as required under this Article or who continues to conduct a home
improvement business after such license has been denied, suspended, revoked or has expired shall be guilty of
a Class A misdemeanor.
Section 863.321. Other Licenses.
1. A license issued pursuant to this Article shall not be construed to authorize the licensee to perform any
particular type of work or kind of business that is reserved to qualified licensees under separate provisions
of State or Local Law.
2. Nothing in this Article shall be construed to limit or restrict the power of a city, town or village to regulate the
quality, performance, or character of the work of contractors including a system of permits and inspections that
are designed to secure compliance with and aid in the enforcement of applicable State and local building laws,
or to enforce other laws necessary for the protection of the public health and safety. Nothing in this Article shall
be construed to limit or restrict the power of a city, town or village to adopt any system of permits requiring
submission to and approval by the city, town or village of plans and specifications for an installation prior to the
commencement of construction of the installation of or inspection of work done.
3. Notwithstanding any provision of this Article to the contrary, this Article shall relate only to the area of the
County of Westchester outside any city, village or area of any town outside the village or villages therein during
such time as such city, village or town is regulating or licensing the home improvement business.
Section 863.322. No Waiver.
The provisions of this Article are intended for the protection of an owner and shall not be subject to
waiver by an owner in a home improvement contract or otherwise.
Section 863.323. Severability.
If any clause, sentence, paragraph or part of this Article shall be adjudged by any court of competent
jurisdiction to be invalid, such judgment shall not affect, impair or invalidate the remainder thereof, but shall be
confined in its operation to the clause, sentence, paragraph, section or part thereof directly involved in the
controversy and in which such judgment shall have been rendered.
Section 863.324. Miscellaneous.
1. Nothing set forth in this Article shall subject the County of Westchester or its officials, agents or employees
to liability for damages or otherwise arising out of or related to the conduct of any home improvement business
by a licensee.
2. The provisions of this Article shall not apply to any home improvement to be performed under a home
improvement contract made prior to the effective date of this Article.
3. Persons engaged in the home improvement business in Westchester County on the effective date of this
Article who have applied for licenses hereunder may continue to engage in such business while their license
applications are processed. Persons not engaged in the home improvement business in Westchester County
on the effective date of this Article may commence such business upon filing a license application in accordance
with Section 863.314 of this Article.
4. Notwithstanding any provisions of this Article to the contrary, this Article shall not apply to:
a. plumbing work;
b. electrical work;
c. architectural services;
d. work or services performed by a person within the scope of an occupation, craft or profession in which
such person has met standards of competency or experience established by State law as a condition to
engaging in the occupation, craft or profession;
e. full-time students under the age of twenty-two (22) engaged in seasonal or part-time employment;
f. the construction of a new home building;
g. the sale of goods or materials by a seller who neither arranges to perform nor performs directly or
indirectly any work or labor in connection with the installation of or application of the goods or materials;
h. work performed upon a residence or building owned by or controlled by the State or any municipality;
i. the sale, leasing, maintaining, installing, repairing, altering, moving, replacing, or servicing of an alarm
device or system by a County-licensed alarm business or alarm agent;
j. The installation of photovoltaic devices by an individual who is licensed as a master electrician pursuant to
Article XVII of Chapter 277 of the Laws of Westchester County and who is also certified as an installer of
photovoltaic devices by the North American Board of Certified Energy Practitioners. For the purpose of this
paragraph “photovoltaic device” means a device that absorbs infrared, visible and/or ultraviolet light and
produces electric potential;
k. The installation of solar heating devices by an individual licensed as a master plumber pursuant to Article
XV of Chapter 277 of the Laws of Westchester County and who is also certified as an installer of solar heating
devices by the North American Board of Certified Energy Practitioners. For the purposes of this paragraph “solar
heating device” means a device that uses flat collector plates to harness the sun’s energy to heat water.
5. The Director or Sealer is empowered to establish administrative procedures to carry out the provisions of
this Article in conformity with the provisions thereof. The Director or Sealer shall require proof of liability and
property damage insurance in an amount to be set by the Director or Sealer.
6. The Director or Sealer may require an application for a license to be accompanied by a bond, approved as
to form by the County Attorney, executed by a bonding or surety company authorized to do business in the
State of New York or cash security in an amount to be set by the Director or Sealer not to exceed fifty thousand
dollars ($50,000.), conditioned upon the assurance that during the term of such license, the contractor will
continue to comply with the provisions of this Article, to assure that upon default in the performance of any
contract, the advance payment made thereon, less the reasonable value of services actually rendered to the
date of the contract in the event of noncompletion thereof, will be refunded to the consumer, owner, or lessee
with whom such contract was made. Such bond shall run to the County of Westchester for the use and benefit
of any person or persons intended to be protected thereby. The required bond, after the aforementioned
approval by the County Attorney, shall be filed in the office of the Director or Sealer. The Director or Sealer may
require a bond at any time during the term of the license based on the licensee's performance during such term.
7. Any licensee using chemicals regulated or controlled by the New York State Department of Environmental
Conservation shall show proof of certification for use of said chemicals.
Section 863.325. Disclosures required of certain home improvement contractors; penalties.
1. If a licensee or an affiliate directly or indirectly arranges or facilitates the financing of a home improvement
contract, then prior to executing the home improvement contract, said licensee must:
a. Disclose to the owner, in writing, any payments made or received by the licensee in connection with the
financing, including the amount of such payments, on forms provided by the Director or Sealer;
b. Provide an appropriate Consumers' Bill of Rights, prepared by the Director or Sealer; and
c. Obtain the owner's written acknowledgement of receipt of the written disclosure of any payments and the
appropriate Consumers' Bill of Rights on forms provided by the Director or Sealer.
2. Within five (5) business days of executing a home improvement contract, any licensee required to comply
with the provisions of subdivision 1, must also file with the Director or Sealer:
a. A copy of the home improvement contract;
b. A copy of the owner's Acknowledgement of Receipt of the written disclosure and the appropriate
Consumers' Bill of Rights.
3. In addition to the penalties set forth in sections 277.171, 277.181 and 863.52, the Director or Sealer may,
after providing notice and an opportunity to be heard, revoke the license or deny the application for a license
renewal that fails to comply with any of the requirements of this section.
Section 863.326. Vehicles to display name and address of landscaper or gardener.
1. All motor vehicles which are used in the normal course of business by landscapers or gardeners or their
employees to deliver tools, materials or workers to a job site in Westchester County shall, while such vehicle is
parked at the job site, display on both sides of the vehicle the names and address of the landscaper or gardener
in letters and numerals readily legible from a distance of fifty feet during daylight hours and while the motor
vehicle is stationary.
2. The requirements of this section may be complied with by permanently affixing the landscaper or gardener’s
name and address to the motor vehicle or by affixing removable signs to the motor vehicle to be displayed while
such vehicle is parked at a job site and the landscapers and gardeners or their employees are engaged in the
normal course of business in Westchester County.
Section 863.327. Leaf Blowers; Licensee Requirements.
1. Effective January 1, 2009, no licensee engaged in the business of landscaping, gardening, arboriculture, or
any similar outdoor vocation, nor its agent, affiliate or employee, shall operate a leaf blower that does not
meet EPA Phase 2, 2007 exhaust emission standards or that does not operate in accordance with
manufacturer’s instructions or specifications.
2. Ninety days from the effective date of this local law, and to the extent practicable, the Director or Sealer
shall notify all licensees and applicants and provide:
(a) copy of this local law regarding the operation of leaf blowers by a contractor or licensee under this
section; and
(b) a copy of EPA Phase 2, 2007 exhaust emission standards.
3. Nothing in this section shall be deemed to supersede any municipal ordinance or rule regulating the use of
leaf blowers or any similar device.
Section 863.328. Seizure and impoundment of vehicles and tools used in connection with the unlicensed
operation of a home improvement business.
1. Any police officer or authorized officer, employee or agent of the Department of Consumer Protection
Weights and Measures, upon service on the operator of a vehicle and/or person in possession of tools or
implements of a notice of violation for operating without a license required by subdivision 1 of section 863.313 of
this article, may seize and impound any vehicle, tool or other implement which such officer has reasonable
cause to believe is being used in connection with such violation. Any vehicle, tool or implement seized pursuant
to this section shall be delivered into the custody of the Department of Public Safety or Department of Consumer
Protection Weights and Measures.
2. A person from whom a vehicle, tool or implement has been seized and impounded pursuant to this section
shall receive notice at the time of such seizure and by overnight mail, as soon thereafter as practical informing
such person how and when the vehicle, tool or implement may be reclaimed. In the event that the person from
whom the vehicle was seized is not the registered owner of the vehicle, separate notice shall be provided by
overnight mail to the registered owner of the vehicle. Notice shall also be provided to any lienholder in the same
manner. For purposes of this section, the term “lienholder” shall, in the case of a vehicle, mean any person,
corporation, partnership, firm, agency, association or other entity who at the time of a seizure pursuant to this
section has a financial interest recorded as a lien with the Department of Motor Vehicles of the State of
New York or any other state, territory, district, province, nation or other jurisdiction.
3. The Director or Sealer or the designee of the Director or Sealer shall hold a hearing in accordance with the
provisions of section 277.151 of the Laws of Westchester County not otherwise in conflict with this section, to
adjudicate the violation of subdivision 1 of section 863.313 of this article underlying the seizure and
impoundment within five business days after the date of such seizure and impoundment and shall render his or
her determination immediately following the conclusion of such hearing. Such determination shall also include a
finding as to whether or not such vehicle, tool or other implement was used in connection with such violation,
and if necessary, an additional finding as to whether the owner of such property, if not the person served with a
notice of violation pursuant to subdivision 1 of this section, permitted the use of such property under
circumstances evincing that such owner knew or should have known that such property would be used for the
conduct that was the basis for the seizure of the property. There shall be a rebuttable presumption that such
owner knew or should have known that such property would be used for the conduct that was the basis for the
seizure of the property, if such owner was the employer, parent, legal guardian or spouse of the person served
with a notice of violation pursuant to subdivision 1 of this section at the time of the seizure.
4. A vehicle, tool or other implement seized and impounded pursuant to this section may be released to the
owner of such property prior to the hearing provided in subdivision 3 of this section upon the posting of an all
cash bond in a form satisfactory to the Director or Sealer in an amount sufficient to cover: (a) the maximum civil
penalties which may be imposed for the violation of subdivision 1 of section 863.313 of this article underlying the
seizure and impoundment; (b) all outstanding civil penalties previously imposed pursuant to Section 277.171 of
the Laws of Westchester County against the person served with a notice of violation pursuant to subdivision 1 of
this section if the authorized agent seizing such property pursuant to subdivision 1 of this section alleges,
based upon reasonable cause to believe, that such owner, if not the person served with a notice of violation
pursuant to subdivision 1 of this section, permitted the use of such property under circumstances evincing that
such owner knew or should have known that such property would be used for the alleged conduct that was the
basis for the seizure of the property; and (c) all reasonable costs for removal and storage of such vehicle, tool or
implement. In addition, release of such vehicle, tool or other implement to the owner of such property shall also
require payment of all outstanding civil penalties previously imposed pursuant to Section 277.171 of the Laws of
Westchester County directly against such owner. Release to a person claiming such property shall be
conditioned on presentation of, in the case of (i) a vehicle, proof of ownership or authorization from the owner of
the vehicle as ownership is defined by section 388 of the Vehicle and Traffic Law, or (ii) in the case of a tool or
other implement or equipment, proof of ownership or authorization by the owner satisfactory to the Director or
Sealer.
5. Following an adjudication that has resulted in a determination that the vehicle, tool or other implement was
used in connection with unlicensed activity in violation of subdivision 1 of section 863.313 of this article, release
of such vehicle, tool or other implement to the owner of such property may be obtained upon payment of: (a) all
civil penalties for the violation of subdivision 1 of section 863.313 of this article underlying the seizure and
impoundment; (b) all outstanding civil penalties previously imposed pursuant to Section 277.171 of the Laws of
Westchester County directly against such owner; (c) all outstanding civil penalties previously imposed pursuant
to Section 277.171 of the Laws of Westchester County against the person served with a notice of violation
pursuant to subdivision 1 of this section if such owner was determined by the Director or Sealer or the
designee of the Director or Sealer pursuant to subdivision 3 of this section, to have permitted the use of such
property by the person served with a notice of violation pursuant to subdivision 1 of this section under
circumstances evincing that such owner knew or should have known that such property would be used for the
conduct that was the basis for the seizure of the property; and (d) all reasonable costs for removal and storage
of such vehicle, tool or implement and proof of ownership as provided in subdivision 4 of this section.
6. No person shall obtain release of a vehicle, tool or other implement pursuant to subdivisions 4 and 5 of this
section, unless and until such person submits an application for a home improvement license, or reinstatement
of such a license, as appropriate, to the Director or Sealer in the form and containing the information required by
the Director or Sealer. Notwithstanding the provisions of this section, in the event that the owner of the vehicle,
tool or other implement was not the person who was served with a notice of violation alleging a violation of the
provisions of subdivision 1 of section 863.313 of this article or found to be in violation of the provisions of
subdivision 1 of section 863.313 of this article, such owner may obtain release upon payment of all applicable
civil penalties and all reasonable costs of removal and storage as provided herein and upon execution of a
sworn statement, subject to the provisions of the Penal Law relative to false statements and satisfactory to the
Director or Sealer, that he or she will not permit the person who is alleged to have violated or found to have
violated such provisions to operate or possess the vehicle, tool or other implement in violation of subdivision 1 of
section 863.313 of this article.
7. After adjudication of the violation underlying the seizure in accordance with subdivision 3 of this section, if
the Director or Sealer or the designee of the Director or Sealer finds that the vehicle, tool or other implement has
not been used in connection with unlicensed activity under the provisions of subdivision 1 of section 863.313 of
this article, the Department of Consumer Protection Weights and Measures shall promptly cause such vehicle,
tool or other implement to be released to its lawful owner upon payment of all outstanding civil penalties
previously imposed pursuant to Section 277.171 of the Laws of Westchester County against such owner. If
applicable, the Department of Consumer Protection Weights and Measures shall also promptly return any
cash bond posted pursuant to subdivision 4 of this section in accordance with the determination of the Director
or Sealer or the designee of the Director or Sealer pursuant to subdivision 3 of this section. Upon demand of
the applicant, the Department of Consumer Protection Weights and Measures shall refund fees, as
appropriate, paid in connection with the submission of an application for a home improvement license pursuant
to subdivision 6 of this section, provided that said applicant withdraws the application, if pending, or otherwise
surrenders any home improvement license previously issued pursuant to such application.
Section 4. This Local Law shall take effect thirty days after it shall have become law.
Section 863.329. Contract provisions
Every home improvement contract and all amendments thereto, shall be in writing and shall be signed
by all parties to the contract. The writing shall be legible, in plain English, and shall be in such a form to
describe clearly any other document which is to be incorporated into the contract. Before any work is done, the
owner shall be furnished a copy of the written agreement, signed by the contractor. The writing may also
contain other matters agreed to by the parties to the contract.
The writing shall contain the following:
(a) The name, address, telephone number and license number of the contractor.
(b) The approximate dates, or estimated dates, when the work will begin and be substantially
completed.
(c) A description of the work to be performed, the materials to be provided to the owner, including
make, model number or any other identifying information.
(d) A notice to the owner purchasing the home improvement that the contractor or subcontractor who
performs on the contract or the material person who provides home improvement goods or services and is not
paid may have a claim against the owner which may be enforced against the property in accordance with the
applicable lien laws.
(e) A notice to the owner purchasing the home improvement that, except as otherwise provided by
law, the home improvement contractor is legally required to deposit all payments received prior to completion in
accordance with subdivision four of section seventy-one-a of the New York State lien law and that, in lieu of
such deposit, the home improvement contractor may post a bond, contract of indemnity or irrevocable letter of
credit with the owner guaranteeing the return or proper application of such payments to the purposes of the
contract.
(f) If the contract provides for one or more progress payments to be paid to the home improvement
contractor by the owner before substantial completion of the work, a schedule of such progress payments
showing the amount of each payment, as a sum in dollars and cents, and specifically identifying the state of
completion of the work or services to be performed, including any materials to be supplied before each such
progress payment is due. The amount of any such progress payments shall bear a reasonable relationship to
the amount of work to be performed, materials to be purchased, or expenses for which the contractor would be
obligated at the time of payment.
Section 863.330. Complaints.
The Director or Sealer shall accept complaints from any person, relating to a Contractor or Home
Improvement Business. In considering an application for a license or renewal under this Chapter, conducting
any investigation, or determining whether to revoke a license granted under this Chapter, the Director or Sealer
may consider any complaints received.
ARTICLE XIX. INSTALLATION AND REPAIR OF OVERHEAD GARAGE DOORS.
Section 863.601. Legislative findings.
The County Board of Legislators finds that overhead garage doors without safety cables attached to them
create a danger to persons and property. Specifically, the springs which facilitate the opening and closing of
overhead garage doors have a tension weight from 75 lbs. to 300 lbs. of pressure. Upon loosening or breaking,
these springs can shoot away from the garage door causing serious injury to persons and damage to property.
The County Board of Legislators further finds that the proper installation of an anchored safety cable can
avoid serious injury or damage by preventing the release of the spring from an overhead garage door.
Therefore, it is in the interest of the welfare and safety of the citizens of Westchester County to require that
home improvement businesses install safety cables upon installation or repair of overhead garage doors.
Section 863.602. Definitions.
1. Home improvement business shall mean a home improvement business licensed pursuant to chapter 863,
article XVI of the Laws of Westchester County.
2. Overhead garage door shall mean any sectional overhead garage door that employs the use of extensions
springs.
3. Person shall mean any natural person, corporation, unincorporated association, firm, partnership, joint
venture, joint stock association or other entity or business organization of any kind.
4. Safety cable shall mean a safety cable no less than three-thirty-seconds (3/32) of an inch which is anchored
from the rear support brackets that hold the garage door track to the front part of the garage door frame.
Section 863.603. Installation and repair of overhead garage doors.
It shall be unlawful for any person or home improvement business to install or repair any overhead garage
door without installing a safety cable, if one does not already exist.
Section 863.604. Violations.
A violation of section 863.603 shall be punishable by a civil fine not to exceed $150.00.
Section 863.605. Severability.
If any clause, sentence, paragraph or part of this article shall be adjudged by any court of competent
jurisdiction to be invalid, such judgment shall not affect, impair or invalidate the remainder thereof, but shall be
confined in its operation to the clause, sentence, paragraph section or part thereof directly involved in the
controversy and in which such judgments shall have been rendered.
ARTICLE XXVI. RESTRICTIONS ON THE APPLICATION AND SALE OF LAWN FERTILIZER WITHIN THE
COUNTY OF WESTCHESTER.
Section 863.1301. Definitions.
(1) “County” means the County of Westchester.
(2) “Commercial fertilizer” means “any substances containing one or more recognized plant nutrients
which is used for its plant nutrient content, and which is designed for use or claimed to have value in promoting
plant growth, except unmanipulated animal or vegetable manures, agricultural liming material, wood ashes,
gypsum and other products exempted by regulation of the New York State Commissioner of Agriculture and
Markets. Any biosolid-based product which is not subject to regulation as a ‘commercial fertilizer’ by the New
York State Department of Agriculture and Markets is not subject to the provisions of this article.”
(3) “Lawn fertilizer” means “a commercial fertilizer distributed primarily for non-farm use, such as lawns,
shrubbery, flowers, golf courses, municipal parks, cemeteries, greenhouses and nurseries, and such other use
as the commissioner may define by regulation. Lawn fertilizer does not include fertilizer products intended
primarily for garden and indoor plant application.”
(4) “Surface water” means “lakes, bays, sounds, ponds, impounding reservoirs, perennial streams and
springs, rivers, creeks, estuaries, marshes, inlets, canals, and all other perennial bodies of surface water,
natural or artificial, inland or coastal, fresh or salt, public or private, but shall not include artificial ponds.”
Section 863.1302. Regulation of the Use and Application of Lawn Fertilizer.
(1) No person shall apply any lawn fertilizer within the County that is labeled as containing more than
0% phosphorus or other compound containing phosphorus, such as phosphate, except as provided in section
863.1303.
(2) No person shall apply lawn fertilizer between December 1st and April 1st.
(3) No person shall apply lawn fertilizer to any impervious surface including parking lots, roadways, and
sidewalks. If such application occurs, the fertilizer must be immediately contained and either legally applied to
turf or placed in an appropriate container.
(4) No person shall apply lawn fertilizer to any turf or lawn area on any real property within twenty (20)
feet of any surface water, except that this restriction shall not apply where a continuous natural vegetative
buffer, at least ten (10) feet wide, separates a turf or lawn area and surface water.
§ 863.1303. Exemptions.
The prohibition against the use of lawn fertilizer under section 863.1302(1) and (4) shall not apply to:
(1) Newly established turf or lawn areas during their first growing season.
(2) Turf or lawn areas that soil tests confirm the need for additional phosphorus application. The lawn
fertilizer application shall not contain an amount of phosphorus exceeding the amount and rate of application
recommended in the soil test evaluation.
(3) Agricultural uses, vegetable and flower gardens, or application to trees or shrubs.
Section 863.1304. Sale of Fertilizer Containing Phosphorus.
(1) No person located and/or doing business within the County of Westchester shall sell or offer for sale
any lawn fertilizer within the County that is labeled as containing more than 0% phosphorus, or other compound
containing phosphorus, such as phosphate, except such fertilizer may be sold for use as provided in section
863.1303.
(2) No person located and/or doing business within the County of Westchester shall display for sale
lawn fertilizer containing phosphorus. Signs may be posted advising customers that lawn fertilizer containing
phosphorus is available upon request for uses permitted by section 863.1303.
(3) Any person located and/or doing business within the County of Westchester, which sells or offers for
sale lawn fertilizer, shall be required, at the location where lawn fertilizers are sold, to post a sign, in the form
provided by the Department of Weights and Measures, containing the regulations set forth in this Article and
explaining the effects of phosphorus and nitrogen on water quality and Westchester County waters.
Section 863.1305. Educational Requirements for Home Improvement Contractors.
Every person who offers to provide or provides lawn or turf services, including, but not limited to,
persons applying for a license to engage in a home improvement business pursuant to Article XVI of this
Chapter, or applying for renewal of a license to engage in a home improvement business pursuant to such
article, and who offer to provide or provide lawn or turf services in the operation of such home improvement
business, shall provide proof of completion of a turf management course approved by the Director or Sealer in
consultation with the Commissioner of the Department of Planning and Westchester County Cornell Cooperative
Extension. The Director or Sealer, in consultation with the Commissioner of the Department of Planning and
Westchester County Cornell Cooperative Extension, may require the participation of such persons at additional
informational seminars and/or courses at reasonable times but no more than once per year in order to ensure
that all such persons are informed of developing issues, technologies, and laws which may impact the
performance of services by such persons in Westchester County. The Director or Sealer, in consultation with the
Commissioner of the Department of Planning, shall have authority to adopt rules and regulations as may be
deemed necessary for the administration and enforcement of this paragraph.
Section 863.1306. Public Education Campaign; Program Monitoring.
(1) The County of Westchester shall undertake a multi-faceted public education campaign, including the
creation of an interactive webpage, aimed at the reduction of non-point source pollution in Westchester County
waterways. Such public education campaign will include the development of best management practices for
lawn and garden care, as well as other strategies for the reduction of nutrient pollution caused by human
activity, and shall specifically address the impacts of nitrogen and phosphorous on water quality in and around
Westchester County.
(2) The County Executive shall cause an evaluation of the effectiveness of the restrictions on fertilizers
under this article to be undertaken and shall further cause an evaluation report to be provided to the County
Board by December 31, 2015.
Section 863.1307. Enforcement and Penalties.
For the first violation of the provisions of this Article or any rule or regulation adopted pursuant to this
Article, a civil penalty not exceeding fifty dollars ($50.00) shall be imposed. For the second and succeeding
violations, a civil penalty not exceeding one hundred fifty dollars ($150.00) shall be imposed for each single
violation. No civil penalty shall be imposed as provided for herein unless the alleged violator has received notice
of the charge against him or her and has had an opportunity to be heard.
Section 863.1308. Reverse preemption.
This chapter shall be null and void on the day that Federal or Statewide legislation goes into effect,
incorporating either the same or substantially similar provisions as are contained in this law, or in the event that
a pertinent state or federal administrative agency issues and promulgates regulations preempting such action by
the County of Westchester. The County Board of Legislators may determine via mere resolution whether or not
identical or substantially similar federal or statewide legislation, or pertinent preempting state or federal
regulations have been enacted for the purposes of triggering the provisions of this section.
Section 863.1309. Separability.
If any section, subsection, sentence, clause, phrase or portion of this local law is for any reason held invalid or
unconstitutional by any court of competent jurisdiction, such portion shall be deemed a separate, distinct and
independent provision and such holding shall not affect the validity of the remaining portions hereof.
Section 2. This Local Law shall take effect immediately, provided that subdivisions (2), (3) and (4) of
Section 863.1302, Section 863.1303 and Section 863.1307 shall take effect on the sixtieth (60th) day after
enactment of this Local Law. Subdivision (3) of Section 863.1304 shall take effect on the one hundred twentieth
(120th) day after the enactment of this Local Law. Section 863.1305 shall take effect on the one hundred
eightieth (180th) day after the enactment of this Local Law. Subdivision (1) of Section 863.1302 and
Subdivisions (1) and (2) of Section 863.1304 shall take effect on January 1, 2011.
ADMINISTRATIVE CODE
ARTICLE VIII: Consumer Policy Board and Consumer Protection
Section 277.171. Enforcement, violations and civil penalties.
1. The hearing officer may impose for each proven violation of the code or for failure to comply with any order
made pursuant thereto a civil penalty not to exceed $1,000.00. Each day that such violation or failure continues
shall constitute a separate offence for which a penalty may be assessed. Any person found by the Director or
Sealer or the designee of the Director or Sealer to be in violation of subdivision 1 of section 863.313 of the
Consumer Code shall be liable for a civil penalty not to exceed $1,000.00 for the first violation; not more than
$5,000.00 for the second violation within a five-year period; and not more than $10,000.00 for the third and all
subsequent violations within a ten-year period. Nothing herein contained shall be construed to exempt an
offender from any other prosecution or penalty imposed by law. The penalty imposed hereunder and the
reasonable costs and expenses attendant to its collection shall be recoverable from the offender in the same
civil action brought by the County Attorney in the name of the County of Westchester.
NEW YORK STATE GENERAL BUSINESS LAW
ARTICLE 36-A
HOME IMPROVEMENT CONTRACTS
Section 770. Definitions.
771. Contract provisions.
771-a. Responsibilities of home improvement contractors.
772. Penalty for fraud.
773. Violations.
774. Action by the attorney general.
775. Applicability.
776. Severability.
§ 770. Definitions. As used in this article, the following terms, unless the context requires otherwise ,
shall have the following meanings:
1. "Person" means a natural person.
2. "Owner" means any homeowner, co-operative shareholder owner, or residential tenant, or any person who
purchases a custom home as defined in this section.
3. "Home improvement" means the repairing, remodeling, altering, converting, or modernizing of, or adding to,
residential property and shall include, but not be limited to, the construction, erection, replacement, or
improvement of driveways, swimming pools, siding, insulation, roofing, windows, terraces, patios, landscaping,
fences, porches, garages, solar energy systems, flooring, basements, and other improvements of the residential
property and all structures or land adjacent to it. "Home improvement" shall also mean the construction of a
custom home, the installation of home improvement goods or the furnishing of home improvement services.
"Home improvement" shall not include:
(a) the sale or construction of a new home, other than a custom home as defined in this section;
(b) the sale of goods by a seller who neither arranges to perform nor performs, directly or indirectly, any work
or labor in connection with the installation or application of the goods;
(c) the sale or installation of appliances, such as stoves, refrigerators, freezers, room air conditioners,
dishwashers, clothes washers or dryers, which are designed to be removable from the premises without
material alteration thereof;
(d) the sale or installation of decorative goods or services, such as draperies and carpets; or
(e) the performance of repairs, replacements, or other services pursuant to an express or implied warranty, or
a maintenance agreement as defined in section three hundred ninety-five-a of this chapter.
4. "Home improvement goods or services" means goods and services which are bought in connection with
home improvement. Such home improvement goods and services include burglar alarms, texture coating,
fencing, air conditioning, heating equipment, and any other goods which, at the time of sale or subsequently, are
to be so affixed to real property by the home improvement contractor as to become a part of real property
whether or not severable therefrom.
5. "Home improvement contractor" means a person, firm or corporation which owns or operates a home
improvement business or who undertakes, offers to undertake or agrees to perform any home improvement for
a fee and for whom the total cash price of all of his home improvement contracts with all his customers exceeds
one thousand five hundred dollars during any period of twelve consecutive months. Home improvement
contractor does not include a person, firm, corporation, landlord, cooperative corporation, condominium board of
managers, joint tenant or co-tenant that owns, in whole or in part, the property to be improved.
6. "Home improvement contract" means an agreement for the performance of home improvement, between a
home improvement contractor and an owner, and where the aggregate contract price specified in one or more
home improvement contracts, including all labor, services and materials to be furnished by the home
improvement contractor, exceeds five hundred dollars.
7. "Custom home" means a new single family residence to be constructed on premises owned of record by
the purchaser at the time of contract, provided that such residence is intended for residential occupancy by such
purchaser and the contract of sale is entered into on or after the first day of March, nineteen hundred ninety.
§ 771. Contract provisions. 1. Every home improvement contract subject to the provisions of this article, and all
amendments thereto, shall be evidenced by a writing and shall be signed by all the parties to the contract. The
writing shall contain the following:
(a) The name, address, telephone number and license number, if applicable, of the contractor.
(b) The approximate dates, or estimated dates, when the work will begin and be substantially completed,
including a statement of any contingencies that would materially change the approximate or estimated
completion date. In addition to the estimated or approximate dates, the contract shall also specify whether or not
the contractor and the owner have determined a definite completion date to be of the essence.
(c) A description of the work to be performed, the materials to be provided to the owner, including make,
model number or any other identifying information, and the agreed upon consideration for the work and
materials.
(d) A notice to the owner purchasing the home improvement that the contractor or subcontractor who
performs on the contract or the materialman who provides home improvement goods or services and is not
paid may have a claim against the owner which may be enforced against the property in accordance with the
applicable lien laws. Such home improvement contract shall also contain the following notice to the owner in
clear and conspicuous bold face type:
"Any contractor, subcontractor, or materialman who provides home improvement goods or services pursuant
to your home improvement contract and who is not paid may have a valid legal claim against your property
known as a mechanic's lien. Any mechanic's lien filed against your property may be discharged. Payment of the
agreed-upon price under the home improvement contract prior to filing a mechanic’s lien may invalidate such
lien. The owner may contact an attorney to determine his rights to discharge a mechanic's lien".
(e) A notice to the owner purchasing the home improvement that, except as otherwise provided in paragraph
(g) of this subdivision, the home improvement contractor is legally required to deposit all payments
received prior to completion in accordance with subdivision four of section seventy-one-a of the lien law and
that, in lieu of such deposit, the home improvement contractor may post a bond, contract of indemnity or
irrevocable letter of credit with the owner guaranteeing the return or proper application of such payments to the
purposes of the contract.
(f) If the contract provides for one or more progress payments to be paid to the home improvement contractor
by the owner before substantial completion of the work, a schedule of such progress payments showing the
amount of each payment, as a sum in dollars and cents, and specifically identifying the state of completion
of the work or services to be performed, including any materials to be supplied before each such
progress payment is due. The amount of any such progress payments shall bear a reasonable relationship to
the amount of work to be performed, materials to be purchased, or expenses for which the contractor would be
obligated at the time of payment.
(g) If the contract provides that the home improvement contractor will be paid on a specified hourly or time
basis for work that has been performed or charges for materials that have been supplied prior to the time that
payment is due, such payments for such work or materials shall not be deemed to be progress payments for the
purposes of paragraph (f) of this subdivision, and shall not be required to be deposited in accordance with the
provisions of paragraph (e) of this subdivision.
(h) A notice to the owner that, in addition to any right otherwise to revoke an offer, the owner may cancel the
home improvement contract until midnight of the third business day after the day on which the owner has signed
an agreement or offer to purchase relating to such contract. Cancellation occurs when written notice of
cancellation is given to the home improvement contractor. Notice of cancellation, if given by mail, shall be
deemed given when deposited in a mailbox properly addressed and postage prepaid. Notice of cancellation
shall be sufficient if it indicates the intention of the owner not to be bound. Notwithstanding the foregoing, this
paragraph shall not apply to a transaction in which the owner has initiated the contact and the home
improvement is needed to meet a bona fide emergency of the owner, and the owner furnishes the home
improvement contractor with a separate dated and signed personal statement in the owner's handwriting
describing the situation requiring immediate remedy and expressly acknowledging and waiving the right to
cancel the home improvement contract within three business days. For the purposes of this paragraph the term
"owner" shall mean an owner or any representative of an owner.
2. The writing shall be legible, in plain English, and shall be in such form to describe clearly any other
document which is to be incorporated into the contract. Before any work is done, the owner shall be furnished a
copy of the written agreement, signed by the contractor. The writing may also contain other matters agreed to by
the parties to the contract.
§ 771-a. Responsibilities of home improvement contractors. No home improvement contractor shall engage
in any activity, transaction, or course of business or pay or receive any fee, payment, money, or other thing of
value in connection with the financing of a home improvement contract without disclosing such activity,
transaction, or course of business and any fees, payment, or other thing of value paid or to be paid in
connection therewith, and without having obtained the agreement in writing from all parties to the transaction to
such activity and the payment therefor.
§ 772. Penalty for fraud. 1. Any owner who is induced to contract for a home improvement, in reliance on
false or fraudulent written representations or false written statements, may sue and recover from such contractor
a penalty of five hundred dollars plus reasonable attorney’s fees, in addition to any damages sustained by the
owner by reason of such statements or representations. In addition, if the court finds that the suit by the owner
was without arguable legal merit, it may award reasonable attorney's fees to the contractor.
2. Nothing in this article shall impair, limit, or reduce the statutory, common law or contractual duties or liability
of any contractor.
§ 773. Violations. 1. Technical violations. Every home improvement contractor who violates any of the
provisions of this article shall be subject to a civil penalty not to exceed one hundred dollars.
2. Substantial violations. Every home improvement contractor who fails to deposit funds in an escrow account
or provide a bond or contract of indemnity or irrevocable letter of credit in compliance with the
requirements of section seventy-one-a of the lien law, or who fails to provide a written contract substantially in
compliance with the requirements of this article, shall be subject to a civil penalty not to exceed the greater of
two hundred fifty dollars for each violation or five percent of the aggregate contract price specified in the home
improvement contract; provided, however, that in no event shall the total penalty exceed twenty-five hundred
dollars for each contract.
3. Mitigating factors; defenses. In an instance where the contractor has been shown to have committed
multiple violations of this article or the provisions of section seventy-one-a of the lien law, the court shall
consider the following factors in assessing a civil penalty pursuant to subdivision two of this section: the volume
of business which the home improvement contractor performs on an annual basis, the number of
contracts in violation, the actual financial loss or exposure to financial loss suffered by any owner as a result of
the violations, and whether the home improvement contractor acted in good faith or willfully with respect to such
violations. No home improvement contractor shall be subject to the increased penalties provided by subdivision
two of this section if such contractor shows by a preponderance of the evidence that the violation was not
intentional and resulted from a bona fide error made notwithstanding the maintenance of procedures reasonably
adopted to avoid such a violation.
§ 774. Action by the attorney general. 1. Upon any violation of the provisions of this article, an application
may be made by the attorney general in the name of the people of the state of New York to a court or justice
having jurisdiction to issue an injunction, and upon notice to the defendant of not less than five days, to enjoin
and restrain the continuance of the violation. If it shall appear to the satisfaction of the court or justice that the
defendant has violated this section, an injunction may be issued by the court or justice, enjoining and restraining
any further violation, without requiring proof that any person has, in fact, been injured or damaged thereby. In
any such proceeding, the court may make allowances to the attorney general as provided in paragraph six of
subdivision (a) of section eight thousand three hundred three of the civil practice law and rules, and direct
restitution.
In connection with an application made under this section, the attorney general is authorized to take proof and
to make a determination of the relevant facts and to issue subpoenas in accordance with the civil practice law
and rules.
2. The provisions of this article may be enforced concurrently by the director of a municipal consumer
affairs office, or by the town attorney, city corporation counsel, or other lawful designee of a municipality or local
government, and all moneys collected thereunder shall be retained by such municipality or local government.
§ 775. Applicability. This article shall not exempt any contractor subject to its provisions from complying with
any local law with respect to the regulation of home improvement contractors, provided, however, that after the
effective date of this article, no political subdivision may enact a local law inconsistent with the provisions of
section seven hundred seventy-one of this article.
§ 776. Severability. If any clause, sentence, paragraph, subdivision or part of this article or the application
thereof to any person, firm or corporation, or circumstance, shall be adjudged by any court of competent
jurisdiction to be invalid or unconstitutional, such judgment shall not affect, impair or invalidate the remainder
thereof, but shall be confined in its operation to the clause, sentence, paragraph, subdivision, or part of this
article; or in its application to the person, firm or corporation, or circumstance, directly involved in the
controversy in which such judgment shall have been rendered.
NEW YORK STATE LIEN LAW
§ 71-a. Further trust of funds received or receivable by owner under executory contract for the sale and
improvement of real property
* * * * * * *
4. (a) Under a home improvement contract, payments received from an owner by a home improvement
contractor prior to the substantial completion of work under the contract shall be deposited within five business
days thereafter by the recipient in an escrow account in a bank, trust company, savings bank, or state or federal
savings and loan association, located in this state. No depository institution acting on the instructions or
otherwise dealing with a home improvement contractor shall be obliged to inquire into the validity or propriety of
any deposits to or withdrawals from any escrow account established by the home improvement contractor in
compliance with this subdivision or to insure that any withdrawals from such account are applied for any specific
purpose or purposes by the home improvement contractor. Such deposit or deposits shall remain the property of
such owner except as otherwise provided herein. [fig 1] Unless the home improvement contract specifies the
name of the depositary where the funds will be placed, no later than ten business days after the deposit has
been made, the recipient shall advise the owner in writing of the name of the depositary where the funds have
been placed. The recipient shall not be required to keep in separate depositary accounts the funds of the
separate owners from whom payments have been received, provided his books of account shall clearly show
the allocation to each owner of the funds deposited in his general or special depositary account or accounts.
(b) In lieu of making the deposit of such payment or payments in an escrow account as provided in paragraph
(a) of this subdivision, the recipient may post with the owner a bond or contract of indemnity, issued by a surety
company licensed to execute such an instrument in this state, or an irrevocable letter of credit issued by a bank,
trust company, savings bank, or state or federal savings and loan institution located in this state, guaranteeing
the return of the payments, or the proper application of the payments to the purposes of the contract, which
otherwise would be required to be deposited in such escrow account, in which case the recipient shall not be
required to deposit such payments in an escrow account. Said bond or contract of indemnity or irrevocable letter
of credit shall be delivered to the owner within ten business days after receipt of the payment.
(c) At any time after making the deposit of such payment or payments in the escrow account, the recipient may
post with the owner a bond or contract of indemnity issued by a surety company licensed to execute such an
instrument in this state, or an irrevocable letter of credit issued by a bank, trust company, savings bank, or state
or federal savings and loan institution located in this state, guaranteeing the return or proper application of such
payment to the purposes of the contract, in which case the recipient shall not be required to maintain the deposit
of such payment in such account.
(d) Such deposit or deposits shall remain the property of the owner or such bond or contract of indemnity or
irrevocable letter of credit continued in effect until (i) the proper payment, transfer or application of such deposits
by the contractor to the purposes of the home improvement contract under the schedule of payments provided
therein; or (ii) the default or breach of the owner excusing the recipient's performance of the terms of the home
improvement contract, but only to the extent of any reasonable liquidated damage amount as defined in section
2-718 of the uniform [fig 1] commercial code and set forth in the contract, and only after seven days prior written
notice to the owner; or (iii) substantial performance of the contract.
(e) The recipient shall not withdraw deposits from the escrow account in excess at any time of the total amount
shown in the schedule of payments in the home improvement contract. The amount of any such progress
payments shall bear a reasonable relationship to the amount of work to be performed, materials purchased, or
expenses for which the contractor would be obligated.
(f) If the home improvement contract provides that the home improvement contractor will be paid on a specified
hourly or time basis for work that has been performed or charges for materials that have been supplied prior to
the time that payment is due, this subdivision shall not apply to such payments for such work or materials.
(g) Failure to place customer deposits in escrow, except as provided herein, shall constitute a violation of this
section.
Child Support Certification
Westchester County Office of Child Support Enforcement
Department of Consumer Protection
THIS FORM MUST BE FULLY COMPLETED BY APPLICANT TO BE VALID
LAST NAME:____________________________________________ FIRST NAME:____________________________________________
SOCIAL SECURITY NO: _________________________________ DATE OF BIRTH: _________________________________________
M M D D Y Y
HOME ADDRESS: ________________________________________________________________________________________________
CITY/STATE/ZIP: ________________________________________________________________________________________________
I, _____________________________________________________, being duly sworn, make the following statement:
(Choose 1 or 2, and put an “X” in the box in front of whichever is appropriate)
1. I am not under a court or administrative order to pay child support. OR
2. I am under an obligation to pay child support. My child support account number is: ______________________________________
(If you chose #2, put an “X” in front of the applicable statement)
A. I do not owe arrears equal to 4 months or more of child support payments.
B. I have arrears equal to 4 months or more of child support payments, and one of the following statements applies to me
(check the appropriate boxes):
I am making payments by income execution or by court agreed payment/re-payment plan or by a plan agreed to by the parties.
My child support obligation is the subject of a pending court proceeding.
I am currently in receipt of Public Assistance or Supplemental Security Income. My case number is: ________________________
C. I have arrears equal to 4 months or more of child support payments and none of the above statements in “B” apply to me.
I hereby do solemnly swear that the information provided by me in this certificate is true and accurate to the best of my knowledge.
I acknowledge that this statement is under oath.
Sworn before me this _____________day X ______________________________________ Date: _____________________
APPLICANT SIGNATURE
of _____________________, _________
__________________________________
Notary Public Signature
State of ___________________________
THE INTENTIONAL SUBMISSION OF FALSE WRITTEN STATEMENTS FOR THE PURPOSE OF FRUSTRATING OR DEFEATING PAYMENT OF
SUPPORT IS PUNISHABLE PURSUANT TO SECTION 175.35 OF THE PENAL LAW. PERSONS WHO ARE FOUR MONTHS OR MORE IN ARREARS IN
CHILD SUPPORT MAY BE SUBJECT TO SUSPENSION OF THEIR BUSINESS, PROFESSIONAL AND/OR DRIVERS LICENSE.
ALL YELLOW FIELDS NOT FILLABLE
LICENSE BEING APPLIED FOR HOME IMPROVEMENT LICENSE
DO NOT WRITE BELOW THIS LINE FOR OFFICIAL USE ONLY
Information verified, or status of case unknown to OCSE. Information is at variance with OCSE records.
Verifying Section & Supervisor: ________________________________________________ Date: _________________
NOTICE
If you are experiencing difficulties obtaining a Westchester County license or permit because of an
outstanding child support problem, and you are making support payments through the Support Collection
Unit of the Westchester County Office of Child Support Enforcement, you may receive assistance in
resolving your problem by contacting:
The Westchester County Office of Child Support Enforcement
100 East First Street, 5
th
Floor
Mount Vernon, New York 10550
1 (888) 208-4485
George Latimer
County Executive
Department of Consumer Protection
James Maisano
Director
John P. Gaccione
Deputy Director
and County Sealer
148 Martine Avenue, Room 407
White Plains, New York 10601 Telephone: (914) 995-2155 Fax: (914) 995-5259 Website: www.westchestergov.com/consumer
1) All contracts must contain the complete exact legal name, address and telephone number of the licensee.
2) The licensee must provide the home improvement contractor's license number in all advertisements, and on all contracts,
change orders, invoices, proposals and stationery.
3) Any home improvement contract, including change orders and amendments, must be in writing and signed by all parties to
the agreement(s).
4) All contracts must contain a date to commence work and a date to complete work under the home improvement contract.
5) All contracts must state in writing the consumer may cancel the contract at any time prior to midnight of the third business
day after the contract is signed.
6) All contracts must contain the Lien Notification as required by Westchester County Law and NYS General Business Law.
7) All deposits taken in anticipation of doing work under a home improvement contract shall be deposited in a designated
escrow account, and written notice as to where these funds will be placed must be given to the owner/client as well.
8) This office must be notified in writing of any changes in the following: Business status, company name and/or address, email
address, phone number(s), applicant’s home address and any and all responsible personnel, within ten days of the change.
9) The Environmental Protection Agency requires any contractor performing renovation, repair and/or painting projects that
disturb lead-based paint in homes built before 1978 must be certified and must follow lead-safe work practices to prevent
lead contamination. For additional information, contact the EPA at 1-800-424-lead (5323).
10) Bumper stickers must be displayed on driver’s side, rear bumper of the vehicle.
11) For any business engaging in landscape and/or gardening work: All motor vehicles used for business purposes must display
the name and address of the company on both sides of the vehicle.
12) For any business engaging in landscape and/or gardening work: You must comply with the regulations concerning the use
and application of lawn fertilizer as specified in New York State Law.
13) All leaf blowers used in the course of business must meet EPA Phase 2, 2007 exhaust emission standards.
14) If this company arranges or facilitates financing of home improvement contracts, you must present the consumer with a copy
of the “Consumer’s Bill of Rights” and Payment Disclosure Form. Copies of the signed disclosure form and contract must be
forwarded to this office within five business days. Disclosure Forms and “Consumer’s Bill of Rights” are available from this
office.
15) All contracts must also be in compliance with any additional regulations and requirements set forth in Westchester County
Law, New York State General Business Law and all other applicable New York State Laws.
16) Failure to comply with any of these instructions is a violation of the laws of Westchester County and/or New York State and
may result in legal action being taken.
THE FOLLOWING IS A BRIEF SUMMARY OF IMPORTANT
REQUIREMENTS RELATED TO HOME IMPROVEMENT
CONTRACTORS. IT SHOULD NOT BE CONSIDERED A SUBSTITUTE
FOR A CONTRACTOR’S RESPONSIBILITY TO BE FAMILIAR WITH ALL
APPLICABLE LEGAL REQUIREMENTS.
12-20
George Latimer
County Executive
Department of Consumer Protection
James Maisano
Director
John P. Gaccione
Deputy Director
and County Sealer
148 Martine Avenue, Room 407
White Plains, New York 10601 Telephone: (914) 995-2155 Fax: (914) 995-5259 Website: www.westchestergov.com/consumer
Credit Card Payment Authorization Form
Sign and complete this form to authorize The Westchester County Department of Consumer
Protection to make a one-time charge to
your credit card listed below.
By signing this form, you give this department permission to debit your account for the amount indicated,
on or after the date this
form is submitted to The Westchester County Department of
Consumer Protection.
Please Complete the Information Below
By
signing below
, I, ___________________________________________________, License # (if applicable): ______________________
authorize
the Westchester County Department of Consumer Protection to charge my credit card
account indicated below for the
amount of Five Hundred Seventy-Five Dollars ($575.00), for the purpose of expediting my Home Improvement License
Application. I understand this is a non-refundable fee and if my application is found deficient or questionable in any way, it will
cause a delay in the expedited process and I will forfeit this fee.
CARDHOLDER SIGNATURE: ____________________________________________ DATE: ___________________________
Cardholder acknowledges receipt of goods and/or services in the amount indicated above and
agrees
to perform the obligations set forth in the cardholder’s agreement with the respective
issuer.
Account
Type:
Visa
MasterCard
AMEX
Discover
Print Cardholder Name (as it appears on card): ______________________________________________________
Account Number: _____________________________________________ Security Code: __________________
Expiration Date: _____________________________________ Account Billing Zip Code: ________________
THIS FORM IS TO BE UTILIZED
ONLY IF YOU ARE SEEKING
TO EXPEDITE THE
APPLICATION PROCESS